Simple Construction Contract

Simple Construction Contract Template for Singapore

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Simple Construction Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

"I need a Simple Construction Contract for a small residential renovation project in Singapore, with a contract value of SGD 150,000 and completion date of March 2025, including specific provisions for sustainable materials and phased payments."

Document background

The Simple Construction Contract is specifically designed for construction projects in Singapore where a comprehensive but uncomplicated agreement is required. This contract type is particularly suitable for smaller to medium-sized construction projects where the scope is well-defined and the relationship between parties is straightforward. It incorporates essential elements required by Singapore construction law while avoiding the complexity of larger construction contracts. The document includes provisions for scope of work, payment terms, timeline, and basic risk allocation, while ensuring compliance with Singapore's Building Control Act and related regulations.

Suggested Sections

1. Parties: Identifies the contracting parties (contractor and client)

2. Background: Context of the construction project and agreement

3. Definitions: Key terms used throughout the contract

4. Scope of Work: Detailed description of construction work to be performed

5. Contract Sum: Price and payment terms

6. Project Timeline: Commencement date, completion date, and key milestones

7. Contractor Obligations: Core responsibilities of the contractor including compliance with Building Control Act and safety regulations

8. Client Obligations: Core responsibilities of the client including access to site and payments

9. Insurance and Indemnity: Required insurance coverage and indemnification provisions

10. Termination: Circumstances and process for contract termination

Optional Sections

1. Variations: Process for handling changes to scope of work - recommended for complex projects

2. Performance Bond: Requirements for performance security - typically for larger projects

3. Liquidated Damages: Predetermined damages for delay in completion - used when time is critical

4. Defects Liability: Period and process for rectifying defects after completion

Suggested Schedules

1. Schedule 1 - Specifications: Detailed technical specifications of the construction work

2. Schedule 2 - Drawings: Architectural and engineering drawings

3. Schedule 3 - Payment Schedule: Breakdown of payment milestones and payment terms

4. Schedule 4 - Project Timeline: Detailed project schedule with milestones and completion dates

5. Schedule 5 - Site Safety Requirements: Safety protocols and requirements under Workplace Safety and Health Act

Authors

Alex Denne

Head of Growth (Open Source Law) @ ��Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Residential Construction
Commercial Construction
Industrial Construction
Small-scale Renovation

Relevant Teams

Construction
Legal
Project Management
Procurement
Finance

Relevant Roles

Construction Manager
Project Manager
Contract Administrator
Site Supervisor
Quantity Surveyor
Legal Counsel
Procurement Manager

Industries

Building Control Act (Chapter 29): Primary legislation governing building works, structural requirements, and construction standards in Singapore

Building and Construction Industry Security of Payment Act (BCISPA): Facilitates payments for construction work done and ensures fair payment terms in the construction industry

Building Maintenance and Strata Management Act: Regulates the maintenance of buildings and common property management

Workplace Safety and Health Act: Ensures safety, health, and welfare of persons at construction workplaces

Building Control (Buildability and Productivity) Regulations: Specific regulations promoting efficient building designs and construction methods

Contract Law (Chapter 53): General contract law principles governing formation and enforcement of contracts in Singapore

Sale of Goods Act (Chapter 393): Governs contracts relating to the sale of construction materials and goods

Limitation Act (Chapter 163): Sets time limits for bringing legal actions relating to construction disputes

Supply of Goods Act: Regulates the quality and fitness for purpose of construction materials and supplies

Environmental Protection and Management Act: Controls environmental impacts of construction activities

Environmental Public Health Act: Manages public health aspects of construction activities including noise and waste management

BCA Regulations: Building and Construction Authority's specific requirements for construction projects

Fire Safety and Shelter Requirements: Mandatory fire safety and civil defense shelter specifications for buildings

URA Guidelines: Urban Redevelopment Authority's planning and development control guidelines

Singapore Standards (SS): Technical standards and specifications for construction works in Singapore

Code of Practice for Building Works: Detailed technical requirements and best practices for construction works

Security of Payment Regulations: Specific regulations under BCISPA governing payment procedures in construction contracts

Construction Industry Payment Adjudication: Dispute resolution mechanism for payment claims in construction projects

Performance Bond Requirements: Regulations governing security bonds required for construction projects

Retention Sum Regulations: Rules governing the withholding and release of retention monies in construction contracts

Public Sector Standard Conditions of Contract (PSSCOC): Standardized contract conditions for public sector construction projects in Singapore

��������Ƶ

How a Sales & Marketing Lead uses ��������Ƶ to reduce contract drafting time by 95%

Let's create your Simple Construction Contract

Authors

Alex Denne

Find the exact document you need

Subcontractor Service Agreement

Subcontractor Employment Agreement

Sole Trader Contract

Simple Subcontractor Contract

Simple Payment Agreement Contract

Residential Contractor Agreement

Pre Agreement Contract

Painting Contract Agreement

Independent Contractor And Non Compete

Foreign Independent Contractor Agreement

Driver Contractor Agreement

Domestic Subcontract Agreement

Contractor Service Agreement

Contractor Referral Agreement

Contract For Personal Service

Contract For Labor Agreement

Contract Between Employer And Independent Contractor

Consulting Agreement Contract

Construction Contractor Contract

Civil Work Contract Agreement

Subcontractor Hold Harmless Agreement

Salon Contract For Employees

Part Time Contractor Agreement

Mining Contractor Agreement

Home Remodel Contract

Framework Agreement Contract

Construction Warranty Agreement

Construction Service Contract

Contract Agreement Between Two Parties

Construction Contract Agreement Form

Binding Agreement Contract

Agreement Security Guard Contract

Agreement For Construction Of House

Agreement Between Contractor And Principal Employer

Independent Contractor Equity Agreement

Model Form Contract

Company Bond Contract

Construction Owner's Representative Contract

Profit Sharing Agreement Independent Contractor

Loan Officer Independent Contractor Agreement

Agreement Between Two Contractors

Security Guard Independent Contractor Agreement

Owner Contractor Agreement

Job Agreement Contract

Home Owners Contract

Cost Plus Contract Form

Contract For Commission Based Employment

Sale Agreement And Construction Agreement

Roofing Contract Agreement

Residential Contractor Contract

Independent Contractor Agreement Real Estate Salesperson

Indemnity Form For Contractors

Flooring Contract Agreement

Delivery Driver Contract Agreement

Employment Contract For Contract Workers

Construction Labor Contract Agreement

Residential Subcontractor Agreement

Temporary Contractor Agreement

Professional Agreement Contract

Exclusive Independent Contractor Agreement

Contract Of Employment Driver

Salesperson Independent Contractor Agreement

General Employment Contract

Driver Subcontractor Agreement

Agreement Contract Between Employer And Employees

Subcontractor Agreement For Professional Services

Short Subcontractor Agreement

Installation Contract Agreement

Independent Contractor Agreement Cleaning Services

Electrical Service Contract

Freelance Employee Contract

Builder Agreement

Party Agreement Contract

Marketing Contractor Agreement

��Ƶ

How a Sales & Marketing Lead uses ��Ƶ to reduce contract drafting time by 95%

�ұ�Ծ��’s Security Promise