Construction Contractor Contract

Construction Contractor Contract Template for Singapore

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Construction Contractor Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

"I need a Construction Contractor Contract for a 20-story commercial building project in Singapore's CBD area, with a contract value of SGD 50 million and completion date of March 2025, including specific provisions for green building certification and sustainable construction methods."

Document background

The Construction Contractor Contract is a fundamental document used in Singapore's construction industry to establish legally binding relationships between principals and contractors. This agreement is essential when engaging contractors for any construction project, whether commercial, residential, or industrial. It incorporates key requirements under Singapore's building control laws, payment security legislation, and workplace safety regulations. The contract typically includes detailed specifications of work, payment structures, timelines, quality standards, and risk allocation mechanisms, while ensuring compliance with Singapore's strict construction industry regulations.

Suggested Sections

1. Parties: Identifies and defines the contracting parties (employer and contractor)

2. Background: Context of the construction project and purpose of the agreement

3. Definitions: Key terms used throughout the contract

4. Scope of Works: Detailed description of construction works to be performed

5. Contract Sum and Payment Terms: Price, payment schedule, and payment conditions in accordance with BCISOPA

6. Project Timeline: Commencement date, completion date, and key milestones

7. Contractor's Obligations: Key responsibilities including safety, quality, and compliance requirements

8. Employer's Obligations: Site access, permits, approvals, and other responsibilities

9. Variations: Process for handling changes to scope or specifications

10. Insurance and Indemnities: Required insurance coverage and indemnification provisions

Optional Sections

1. Performance Bond: Required for larger projects or when financial security is needed - typically used for projects above certain value threshold

2. Liquidated Damages: Predetermined damages for delay or non-performance - typically used for time-critical projects

3. Defects Liability: Extended warranty period and remediation process - typically used for complex construction works

4. Environmental Compliance: Specific environmental requirements and standards - used for projects with environmental impact

Suggested Schedules

1. Schedule 1 - Scope of Works: Detailed specifications, drawings, and requirements

2. Schedule 2 - Project Timeline: Detailed project schedule and milestones

3. Schedule 3 - Payment Schedule: Breakdown of payments and payment milestones

4. Schedule 4 - Site Details: Site plans, access points, and restrictions

5. Schedule 5 - Insurance Requirements: Detailed insurance specifications and coverage limits

6. Appendix A - Technical Specifications: Detailed technical requirements and standards

7. Appendix B - Safety Requirements: Safety protocols and requirements

8. Appendix C - Quality Control Plan: Quality assurance and control procedures

Authors

Alex Denne

Head of Growth (Open Source Law) @ ��Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Commercial Real Estate
Residential Development
Industrial Construction
Infrastructure
Institutional

Relevant Teams

Legal
Operations
Procurement
Finance
Risk Management
Quality Assurance

Relevant Roles

Project Manager
Construction Manager
Contract Manager
Legal Counsel
Procurement Manager
Chief Financial Officer

Industries

Building Control Act (Chapter 29): Primary legislation that regulates building works and construction, sets safety and structural requirements, and governs building plan approval requirements

Building and Construction Industry Security of Payment Act (BCISOPA): Regulates payment terms and disputes in construction contracts, including progress payment provisions and adjudication process

Workplace Safety and Health Act: Governs safety requirements at construction sites, risk management requirements, and penalties for non-compliance

Employment Act: Covers labor laws affecting workers, working hours and conditions, and foreign worker regulations in Singapore

Contract Law (Common Law): Governs formation of contracts, terms and conditions, and remedies for breach under Singapore's common law system

Building Control Regulations: Subsidiary legislation providing detailed requirements for building control and construction

Building Control (Buildability and Productivity) Regulations: Specific regulations focusing on construction efficiency and productivity requirements

Building Maintenance and Strata Management Act: Legislation governing the maintenance of buildings and management of common property

Fire Safety Act: Regulates fire safety requirements and standards in construction

SIA Form of Contract: Professional guidelines and standard form contracts provided by Singapore Institute of Architects

Public Sector Standard Conditions of Contract (PSSCOC): Standard contract conditions for public sector construction projects in Singapore

BCA Guidelines: Building and Construction Authority's guidelines for construction practices and standards

Environmental Protection and Management Act: Environmental laws and regulations affecting construction projects

Planning Act: Regulations regarding planning permissions and development requirements

Singapore Standards (Construction): Quality and standards requirements specific to construction industry

Insurance Act: Regulations governing mandatory insurance requirements for construction projects

Arbitration Act: Framework for dispute resolution mechanisms in construction contracts

��������Ƶ

How a Sales & Marketing Lead uses ��������Ƶ to reduce contract drafting time by 95%

Let's create your Construction Contractor Contract

Authors

Alex Denne

Find the exact document you need

Subcontractor Service Agreement

Subcontractor Employment Agreement

Sole Trader Contract

Simple Subcontractor Contract

Simple Payment Agreement Contract

Residential Contractor Agreement

Pre Agreement Contract

Painting Contract Agreement

Independent Contractor And Non Compete

Foreign Independent Contractor Agreement

Driver Contractor Agreement

Domestic Subcontract Agreement

Contractor Service Agreement

Contractor Referral Agreement

Contract For Personal Service

Contract For Labor Agreement

Contract Between Employer And Independent Contractor

Consulting Agreement Contract

Construction Contractor Contract

Civil Work Contract Agreement

Subcontractor Hold Harmless Agreement

Salon Contract For Employees

Part Time Contractor Agreement

Mining Contractor Agreement

Home Remodel Contract

Framework Agreement Contract

Construction Warranty Agreement

Construction Service Contract

Contract Agreement Between Two Parties

Construction Contract Agreement Form

Binding Agreement Contract

Agreement Security Guard Contract

Agreement For Construction Of House

Agreement Between Contractor And Principal Employer

Independent Contractor Equity Agreement

Model Form Contract

Company Bond Contract

Construction Owner's Representative Contract

Profit Sharing Agreement Independent Contractor

Loan Officer Independent Contractor Agreement

Agreement Between Two Contractors

Security Guard Independent Contractor Agreement

Owner Contractor Agreement

Job Agreement Contract

Home Owners Contract

Cost Plus Contract Form

Contract For Commission Based Employment

Sale Agreement And Construction Agreement

Roofing Contract Agreement

Residential Contractor Contract

Independent Contractor Agreement Real Estate Salesperson

Indemnity Form For Contractors

Flooring Contract Agreement

Delivery Driver Contract Agreement

Employment Contract For Contract Workers

Construction Labor Contract Agreement

Residential Subcontractor Agreement

Temporary Contractor Agreement

Professional Agreement Contract

Exclusive Independent Contractor Agreement

Contract Of Employment Driver

Salesperson Independent Contractor Agreement

General Employment Contract

Driver Subcontractor Agreement

Agreement Contract Between Employer And Employees

Subcontractor Agreement For Professional Services

Short Subcontractor Agreement

Installation Contract Agreement

Independent Contractor Agreement Cleaning Services

Electrical Service Contract

Freelance Employee Contract

Builder Agreement

Party Agreement Contract

Marketing Contractor Agreement

��Ƶ

How a Sales & Marketing Lead uses ��Ƶ to reduce contract drafting time by 95%

�ұ�Ծ��’s Security Promise