1. Parties: Identification of the Employer and the Contractor, including their legal details and registered addresses
2. Background: Context of the agreement, project overview, and basis for the contract
3. Definitions and Interpretation: Detailed definitions of terms used throughout the agreement and rules of interpretation
4. Scope of Work: Comprehensive description of the works to be performed, including design, procurement, construction, and commissioning
5. Contract Price and Payment Terms: Total contract value, payment schedule, milestones, and payment conditions
6. Project Timeline: Commencement date, completion deadline, key milestones, and extension mechanisms
7. Contractor's Obligations: Detailed responsibilities including design, procurement, construction, testing, and commissioning
8. Employer's Obligations: Responsibilities of the employer including site access, permits, and approvals
9. Quality Assurance and Control: Quality standards, inspection procedures, and compliance requirements
10. Testing and Commissioning: Procedures for testing, performance trials, and acceptance criteria
11. Completion and Handover: Requirements for substantial completion, final completion, and project handover
12. Warranties and Defects Liability: Warranty terms, defects notification period, and remedial obligations
13. Risk and Insurance: Risk allocation, required insurance coverage, and liability provisions
14. Force Majeure: Definition of force majeure events and their consequences
15. Changes and Variations: Procedures for handling changes to scope, price, or timeline
16. Suspension and Termination: Rights and procedures for contract suspension or termination
17. Dispute Resolution: Procedures for resolving disputes, including arbitration provisions
18. Governing Law and Jurisdiction: Specification of Swiss law as governing law and jurisdiction details
19. Miscellaneous: Standard boilerplate provisions including notices, assignment, and severability
