The Contract For Building A House is a crucial legal document used in Qatar's construction industry when a property owner engages a contractor to construct a residential property. This agreement is essential for protecting both parties' interests and ensuring compliance with Qatar's strict construction and building regulations. The document incorporates requirements from the Qatar Civil Code, Construction Specifications (QCS 2014), and relevant municipality regulations. It typically includes comprehensive details about construction specifications, payment terms, timelines, quality standards, and dispute resolution procedures. The contract should be used whenever a residential construction project is initiated in Qatar, whether for private villas, family homes, or similar residential structures.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the Owner/Employer and the Contractor, including full legal names and addresses
2. Background: Context of the agreement, including property details and construction purpose
3. Definitions: Detailed definitions of terms used throughout the contract
4. Scope of Work: Detailed description of the construction work to be performed
5. Contract Price and Payment Terms: Total contract value, payment schedule, and payment conditions
6. Project Timeline: Construction schedule, completion date, and milestone dates
7. Contractor's Obligations: Detailed responsibilities of the contractor including quality standards, safety measures, and compliance requirements
8. Owner's Obligations: Responsibilities of the owner including site access, permits, and approvals
9. Materials and Workmanship: Specifications for construction materials and quality standards
10. Variations and Changes: Procedures for handling changes to the scope of work
11. Inspections and Approvals: Process for work inspection, testing, and approval procedures
12. Warranties and Defects Liability: Warranty terms and process for addressing defects
13. Insurance and Indemnities: Required insurance coverage and indemnification provisions
14. Force Majeure: Provisions for unforeseen circumstances and their handling
15. Termination: Grounds and procedures for contract termination
16. Dispute Resolution: Procedures for resolving disputes including arbitration provisions
17. Governing Law: Specification of Qatar law as governing law and jurisdiction
1. Sustainable Building Requirements: Include when the project must meet specific green building standards or sustainability certifications
2. Subcontracting: Include when subcontractors will be used, specifying approval requirements and contractor's liability
3. Site Security: Include for projects in sensitive areas or with specific security requirements
4. Utilities and Services: Include when specific arrangements are needed for utility connections and services
5. Temporary Facilities: Include when temporary structures or facilities are required during construction
6. Archaeological Discoveries: Include for sites where archaeological discoveries are possible
7. Environmental Protection Measures: Include when specific environmental protection requirements apply
8. Financing Arrangements: Include when project involves specific financing or payment arrangements
1. Schedule 1 - Construction Drawings and Plans: Detailed architectural and engineering drawings approved for construction
2. Schedule 2 - Technical Specifications: Detailed technical specifications for all construction elements
3. Schedule 3 - Bill of Quantities: Itemized list of materials and works with quantities and prices
4. Schedule 4 - Payment Schedule: Detailed breakdown of payment milestones and amounts
5. Schedule 5 - Construction Timeline: Detailed project schedule with milestones and critical path
6. Schedule 6 - Quality Assurance Plan: Specific quality control measures and testing requirements
7. Schedule 7 - Site Safety Plan: Detailed safety procedures and requirements
8. Schedule 8 - List of Approved Materials: Specific materials approved for use in construction
9. Schedule 9 - Forms and Certificates: Standard forms for variations, completion certificates, and other documentation
10. Schedule 10 - Insurance Requirements: Detailed insurance specifications and coverage requirements
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate
Architecture
Engineering
Interior Design
Building Materials
Construction Management
Property Development
Insurance
Banking and Finance
Relevant Teams
Legal
Construction
Project Management
Real Estate
Architecture
Engineering
Procurement
Finance
Risk Management
Quality Assurance
Health and Safety
Operations
Relevant Roles
Construction Manager
Project Director
Legal Counsel
Contract Manager
Property Developer
Real Estate Manager
Architect
Civil Engineer
Quantity Surveyor
Risk Manager
Procurement Manager
Site Supervisor
Quality Control Manager
HSE Manager
Finance Director
Insurance Manager
Find the exact document you need
Contractor Client Contract
A Qatar law-governed agreement between client and contractor defining service provision terms, obligations, and compliance requirements.
Download
Renovation Contract Agreement
A Qatar law-governed agreement establishing terms and conditions for property renovation works, compliant with local construction regulations and civil code requirements.
Download
Contractor Client Agreement
A Qatar law-governed agreement establishing terms and conditions between a client and contractor for specific services or works.
Download
Agreement Between Owner And Electrical Contractor
A Qatar-law governed agreement between owner and electrical contractor for electrical works, compliant with local regulations and Kahramaa requirements.
Download
House Building Contract Agreement
A Qatar-law governed agreement setting out terms and conditions for residential property construction between a property owner and contractor.
Download
Freelance Contractor Agreement
Qatar-law governed agreement establishing terms and conditions between a client and independent contractor for professional services.
Download
Sole Trader Contract
A Qatar-law compliant contract template for sole traders engaging in business relationships with clients, incorporating key commercial and legal requirements.
Download
Simple Subcontractor Agreement
A Qatar law-governed agreement between contractor and subcontractor defining work scope, payment terms, and compliance requirements.
Download
Simple Payment Agreement Contract
A Qatar law-governed agreement establishing payment terms and obligations between parties, with clear payment schedules and enforcement provisions.
Download
Labour Hire Contract
Qatar-compliant Labour Hire Contract template establishing employment terms between labor hire company, worker, and host employers, incorporating recent Qatar labor reforms.
Download
Contract For Labor Agreement
A comprehensive employment agreement compliant with Qatar Labor Law, establishing terms and conditions between employer and employee in Qatar.
Download
Consulting Agreement Contract
A Qatar law-governed agreement establishing the terms and conditions for consulting services between a consultant and client, ensuring compliance with local regulations while protecting both parties' interests.
Download
Salon Contract For Employees
Qatar-compliant employment contract template for salon professionals, addressing beauty industry specifics and local labor law requirements.
Download
Home Remodel Contract
A Qatar-law governed contract for residential property renovation works, defining terms between homeowner and contractor.
Download
General Contract Agreement Between Two Parties
A comprehensive General Contract Agreement template compliant with Qatari law, designed for establishing contractual relationships between two parties operating within Qatar's jurisdiction.
Download
Framework Agreement Contract
Qatar law-governed master agreement establishing terms for ongoing business relationships and future transactions between parties.
Download
Carpenter Contract Agreement
Qatar-governed agreement outlining terms and conditions for carpentry services, including scope, payment, and obligations under Qatar law.
Download
Plumbing Work Agreement
A Qatar law-governed agreement setting out terms and conditions for plumbing works, including scope, payment, and quality requirements.
Download
Owner's Representative Agreement
Qatar-governed agreement appointing a representative to act on behalf of an owner in managing and overseeing project or property development activities.
Download
Labor Contract Form
A standardized employment agreement compliant with Qatar Labor Law, establishing terms and conditions of employment between employer and employee in Qatar.
Download
Simple Service Agreement Contract
A Qatar law-compliant service agreement template for establishing clear terms between service providers and clients, incorporating local legal requirements and business practices.
Download
Short Form Contract Between Owner And Contractor
Qatar-law governed construction agreement establishing core rights and obligations between owner and contractor for straightforward construction projects.
Download
Subcontractor Framework Agreement
A Qatar law-governed master agreement establishing terms for ongoing subcontracting relationships, enabling multiple work orders under a single framework.
Download
Simple Business Agreement Contract
A Qatar law-governed agreement establishing fundamental terms and conditions for business relationships between parties operating in Qatar.
Download
Landscaping Contract Agreement
Qatar-governed agreement for landscaping services, covering design, implementation, and maintenance of outdoor spaces, with compliance to local regulations.
Download
Builder Agreement
A Qatar law-governed construction contract between owner and builder, detailing construction terms and regulatory compliance requirements.
Download
Salon Agreement Contract
A Qatar-law governed agreement establishing terms and conditions for beauty salon operations, including premises usage, operational requirements, and regulatory compliance.
Download
Owner Agreement Contract
A Qatar law-governed agreement establishing ownership rights and obligations between business partners, compliant with local commercial regulations.
Download
Legal Agreement Contract
A Qatar law-governed legal agreement establishing contractual relationships between parties, incorporating local legal requirements and Sharia principles.
Download
International Contractor Agreement
Qatar law-governed agreement establishing terms between a Qatar-based entity and an international contractor, ensuring compliance with local regulations and commercial requirements.
Download
House Painting Contract
Qatar-law governed contract template for professional painting services, outlining terms, conditions, and compliance requirements for residential or commercial properties.
Download
Contract For Building A House
Qatar-law governed agreement for residential property construction, establishing terms between property owner and contractor.
Download
Exclusive Contractor Agreement
Qatar law-governed agreement establishing an exclusive contractual relationship between a service recipient and contractor, defining exclusive service provision terms and obligations.
Download
Basic Building Contract
A Qatar law-governed construction agreement establishing core rights and obligations between employer and contractor for building projects.
Download
Fabrication Contract Agreement
A Qatar law-governed agreement establishing terms for custom fabrication services, including technical specifications, quality standards, and regulatory compliance requirements.
Download
Home Improvement Contract Agreement
A Qatar-law governed agreement between homeowner and contractor for residential improvement works, detailing project scope, terms, and compliance requirements.
Download
Liability Agreement Contract
A Qatar law-governed agreement defining liability terms, risk allocation, and indemnification obligations between contracting parties.
Download
Electrical Work Contract Agreement
Qatar-governed agreement for electrical works, defining scope, specifications, and obligations between client and contractor under Qatari law.
Download
Work Order Contract
A Qatar law-governed contract defining terms and conditions for specific work or services, detailing scope, payment, and performance requirements.
Download
Work Agreement Contract
Qatar-law compliant employment agreement establishing terms and conditions of employment relationship between employer and employee.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)