Ƶ

Engineering Procurement And Construction Agreement for Malaysia

Engineering Procurement And Construction Agreement Template for Malaysia

A comprehensive agreement governed by Malaysian law that establishes the legal framework for the engineering, procurement, and construction of major projects. This document defines the complete scope of work, responsibilities, and obligations of both the employer and contractor, including detailed technical specifications, commercial terms, project timelines, and performance requirements. It incorporates Malaysian regulatory requirements, local content provisions, and industry standards while addressing risk allocation, payment mechanisms, and dispute resolution procedures specific to the Malaysian jurisdiction.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Download a Standard Template

4.6 / 5
4.8 / 5
Access for free
OR

Alternatively: Run an advanced review of an existing
Engineering Procurement And Construction Agreement

Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

What is a Engineering Procurement And Construction Agreement?

The Engineering Procurement And Construction Agreement is a crucial document for major capital projects in Malaysia, typically used for complex industrial, infrastructure, or energy facilities where single-point responsibility is required. This agreement type is particularly relevant when the project owner (Employer) wants to transfer the majority of project risks to a single contractor who takes full responsibility for design, procurement, and construction through to completion. The document must comply with Malaysian laws including the Street, Drainage and Building Act 1974, Registration of Engineers Act 1967, and relevant environmental regulations. It includes comprehensive technical specifications, commercial terms, performance guarantees, and project execution requirements while incorporating local content requirements and industry standards. This agreement type is commonly used in sectors such as power generation, oil and gas, and infrastructure development where project complexity demands detailed risk allocation and performance requirements.

What sections should be included in a Engineering Procurement And Construction Agreement?

1. Parties: Identification and details of the contracting parties including Employer and Contractor

2. Background: Project context, purpose, and basic understanding between parties

3. Definitions and Interpretation: Detailed definitions of terms used and rules for contract interpretation

4. Scope of Work: Detailed description of engineering, procurement, and construction obligations

5. Contract Price and Payment: Price structure, payment terms, milestones, and invoicing procedures

6. Project Schedule: Timeline, key milestones, completion dates, and delay consequences

7. Contractor Obligations: Detailed responsibilities including permits, materials, workmanship standards

8. Employer Obligations: Responsibilities including site access, approvals, and information provision

9. Quality and Standards: Required quality levels, testing procedures, and applicable standards

10. Changes and Variations: Procedures for handling changes to scope, price, or schedule

11. Testing and Completion: Commissioning procedures, acceptance tests, and completion certificates

12. Defects Liability: Warranty period, remedial obligations, and defect correction procedures

13. Risk and Insurance: Risk allocation and required insurance coverage

14. Force Majeure: Definition of force majeure events and consequences

15. Termination: Grounds for termination and consequences

16. Disputes Resolution: Procedures for resolving disputes including arbitration

17. Governing Law: Malaysian law as governing law and jurisdiction provisions

What sections are optional to include in a Engineering Procurement And Construction Agreement?

1. Performance Security: Requirements for performance bonds or guarantees, used for high-value projects

2. Intellectual Property: IP rights and licenses, important for projects involving proprietary technology

3. Environmental Compliance: Specific environmental obligations, needed for environmentally sensitive projects

4. Local Content Requirements: Malaysian content requirements, relevant for government or regulated projects

5. Interface Management: Procedures for managing multiple contractors, needed for complex projects

6. Training and Technology Transfer: Requirements for training employer's personnel, relevant for specialized facilities

7. Spare Parts and Maintenance: Long-term maintenance obligations, important for operational facilities

8. Step-in Rights: Employer's right to take over work, relevant for critical infrastructure projects

What schedules should be included in a Engineering Procurement And Construction Agreement?

1. Schedule 1 - Scope of Work: Detailed technical specifications and scope breakdown

2. Schedule 2 - Project Schedule: Detailed timeline with all milestones and critical paths

3. Schedule 3 - Price Schedule: Detailed pricing breakdown and payment milestones

4. Schedule 4 - Site Information: Site details, conditions, and access requirements

5. Schedule 5 - Testing and Commissioning: Detailed testing procedures and acceptance criteria

6. Schedule 6 - Forms of Certificates: Templates for various certificates including completion certificates

7. Schedule 7 - Key Personnel: List of key personnel and their responsibilities

8. Schedule 8 - Forms of Securities: Templates for bonds and guarantees

9. Schedule 9 - Insurance Requirements: Detailed insurance specifications

10. Schedule 10 - HSE Requirements: Health, safety, and environmental requirements

11. Appendix A - Technical Specifications: Detailed technical requirements and standards

12. Appendix B - Drawings: Project drawings and designs

13. Appendix C - Permits and Licenses: List of required permits and responsible parties

Authors

Alex Denne

Head of Growth (Open Source Law) @ Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Jurisdiction

Malaysia

Publisher

Ƶ

Document Type

Project Agreement

Cost

Free to use
Relevant legal definitions





















































Clauses








































Relevant Industries

Oil and Gas

Power Generation

Renewable Energy

Chemical and Petrochemical

Infrastructure Development

Industrial Manufacturing

Mining and Resources

Water Treatment

Waste Management

Transportation Infrastructure

Data Centers

Healthcare Facilities

Relevant Teams

Legal

Engineering

Procurement

Construction

Commercial

Finance

Risk Management

Project Controls

Quality Assurance

Health Safety Environment

Operations

Technical Services

Contract Administration

Relevant Roles

Project Director

Contract Manager

Engineering Manager

Procurement Manager

Construction Manager

Legal Counsel

Commercial Director

Technical Director

Risk Manager

Finance Director

Project Controls Manager

Quality Assurance Manager

HSE Manager

Operations Director

Chief Executive Officer

Chief Financial Officer

Project Sponsor

Industries












Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Build Agreement

A Malaysian law-governed construction contract establishing terms and conditions between developer and contractor for building works in Malaysia.

Download

Commercial In Confidence Agreement

A Malaysian law-governed confidentiality agreement protecting sensitive business information shared during commercial relationships.

Download

Remodeling Agreement

A Malaysian law-governed agreement setting out terms and conditions for property renovation works between a contractor and property owner.

Download

Design And Build Agreement

A Malaysian law-governed agreement combining design and construction responsibilities under a single contract, establishing comprehensive project delivery terms.

Download

Agreement For Demolition Of Building

A Malaysian law-governed agreement establishing terms and conditions for building demolition, including safety, environmental, and regulatory requirements.

Download

Project Financing Agreement

A Malaysian law-governed agreement establishing terms and conditions for project financing, including lending arrangements, security package, and compliance requirements.

Download

Non Disclosure Agreement For Design Work

Malaysian-law NDA specifically crafted for protecting confidential information in design projects and creative works.

Download

Home Construction Agreement

A Malaysian law-governed agreement setting out terms and conditions between a homeowner and contractor for residential construction works.

Download

Design Build Maintain Contract

Malaysian law-governed contract template combining design, construction, and maintenance obligations for infrastructure projects.

Download

Agreement In Business Proposal

A Malaysian law-governed agreement that formalizes a business proposal, combining detailed commercial offerings with binding contractual provisions.

Download

Project Based Agreement

A Malaysian law-governed agreement establishing terms and conditions for project-based work, including scope, deliverables, and responsibilities.

Download

Project Agreement Between Two Companies

A Malaysian law-governed agreement establishing project terms and conditions between two companies, including scope, responsibilities, and deliverables.

Download

Mining Concession Agreement

A legal agreement under Malaysian law granting rights to explore and extract mineral resources, subject to federal and state mining regulations.

Download

Consortium Partnership Agreement

A Malaysian law-governed agreement establishing a consortium partnership between multiple parties, defining their rights, responsibilities, and operational framework.

Download

Swimming Pool Construction Agreement

A Malaysian law-governed agreement for swimming pool construction, specifying contractor and owner obligations, technical requirements, and project terms.

Download

Design Build Contract

Malaysian law-governed contract template combining design and construction responsibilities under a single agreement, compliant with local construction regulations.

Download

Operation And Maintenance Agreement Solar Power Plant

A Malaysian law-governed agreement establishing operational and maintenance parameters for solar power plants, aligned with local energy regulations and industry standards.

Download

Subcontractor Work Agreement

A Malaysian law-governed agreement establishing terms and conditions for subcontractor services, including scope, payment, and performance requirements.

Download

Construction Subcontracts

Malaysian construction subcontract agreement establishing terms between main contractor and subcontractor, compliant with local construction laws and regulations.

Download

Project Support Agreement

A Malaysian law-governed agreement establishing terms for project support services, including scope, responsibilities, and commercial terms.

Download

Project Management Agreement

A Malaysian law-governed agreement establishing terms and conditions for professional project management services between a client and project manager.

Download

Project Alliance Agreement

A Malaysian law-governed agreement establishing a collaborative framework for multiple parties to deliver complex projects through shared risks and rewards.

Download

Construction Agreement Between Owner And Contractor

A Malaysian law-governed agreement between property owner and contractor defining terms, conditions, and obligations for construction works.

Download

Consortium Agreement Construction Project

Malaysian-law governed agreement establishing a construction consortium, defining member relationships, obligations, and project execution framework.

Download

Building Work Agreement

Malaysian-law governed construction agreement setting out terms and conditions between property owner/developer and contractor for building works.

Download

Project Profit Sharing Agreement

A Malaysian law-governed agreement establishing profit sharing arrangements between parties for a specific project, including calculation methods and distribution mechanisms.

Download

Project Implementation Agreement

A Malaysian law-governed agreement defining the framework for project execution, including parties' obligations, deliverables, and implementation requirements.

Download

Project Delivery Agreement

A Malaysian law-governed agreement establishing terms and conditions for project delivery between client and contractor, including scope, responsibilities, and commercial terms.

Download

Build Own Transfer Agreement

Malaysian-law governed Build Own Transfer Agreement for infrastructure development projects, covering construction, operation, and transfer phases.

Download

Project Agreement Between Company And Client

A Malaysian law-governed agreement establishing terms between a service provider and client for project execution, detailing scope, deliverables, and mutual obligations.

Download

Pilot Project Agreement

A Malaysian law-governed agreement for establishing and managing pilot projects, defining scope, responsibilities, and success criteria between participating parties.

Download

Minor Works Agreement

A Malaysian law-governed agreement for minor construction and renovation works, establishing terms between employer and contractor.

Download

Project Service Agreement

A Malaysian law-governed agreement defining terms and conditions for project-based service delivery between a service provider and client.

Download

Joint Venture Agreement For Land Development

A Malaysian-law compliant agreement governing joint venture arrangements for property development projects, including land rights, development obligations, and regulatory compliance.

Download

Construction Project Agreement

A legally binding agreement under Malaysian law governing construction projects, detailing obligations, scope, payments, and compliance requirements for all involved parties.

Download

Road Construction Agreement

A Malaysian law-governed agreement for road construction projects, detailing construction terms, specifications, and regulatory compliance requirements.

Download

Project Funding Agreement

A Malaysian law-governed agreement establishing terms and conditions for project funding, including funding mechanics, obligations, and security arrangements.

Download

Engineering Procurement And Construction Agreement

A Malaysian law-governed agreement for comprehensive engineering, procurement, and construction projects, defining complete project delivery obligations and risk allocation.

Download

Project Cooperation Agreement

A Malaysian law-governed agreement establishing terms and framework for multi-party project collaboration and execution.

Download

Project Agreement Contract

A Malaysian law-governed agreement establishing terms and conditions for project execution between principal and contractor, including scope, timeline, payments, and responsibilities.

Download
See more related templates

ұԾ’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; ұԾ’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

We are ISO27001 certified, so your data is secure

Organizational security:

You retain IP ownership of your documents and their information

You have full control over your data and who gets to see it