1. Parties: Identification of the contracting parties including the employer/client and the contractor, with their full legal names and registered addresses
2. Background: Context of the agreement, brief project description, and purpose of the contract
3. Definitions and Interpretation: Definitions of key terms used throughout the agreement and rules of interpretation
4. Scope of Works: Detailed description of the construction works to be performed, including general obligations of the contractor
5. Contract Price and Payment Terms: Agreement on contract price, payment schedule, variation procedures, and payment mechanisms in compliance with CIPAA 2012
6. Project Timeline: Commencement date, completion date, project milestones, and provisions for extensions of time
7. Contractor's Obligations: Detailed responsibilities including workmanship, materials, compliance with laws, and site management
8. Employer's Obligations: Client's responsibilities including site access, permits, approvals, and information provision
9. Quality and Standards: Required quality standards, inspection procedures, and acceptance criteria
10. Health, Safety and Environment: HSE requirements, compliance with regulations, and safety management procedures
11. Variations: Procedures for handling changes to scope, price adjustments, and variation orders
12. Insurance and Indemnities: Required insurance coverage and indemnification obligations
13. Defects Liability: Defects liability period, rectification procedures, and warranties
14. Force Majeure: Definition of force majeure events and consequential procedures
15. Termination: Grounds for termination, termination procedures, and consequences
16. Dispute Resolution: Dispute resolution procedures including mediation, adjudication under CIPAA, and arbitration
17. Governing Law: Specification of Malaysian law as governing law and jurisdiction
18. General Provisions: Standard boilerplate clauses including notices, assignment, and entire agreement
