¶¶Òõ¶ÌÊÓƵ

All Countries
Real Estate
General Contractor Contract

General Contractor Contract Template for Qatar

Create a bespoke document in minutes,  or upload and review your own.

4.6 / 5
4.8 / 5

Let's create your General Contractor Contract

Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

General Contractor Contract

"I need a General Contractor Contract for a large-scale commercial development project in Doha, Qatar, with specific provisions for sustainable building practices and strict completion deadlines by March 2025, including substantial liquidated damages clauses."

Celebrated by
Collaborations with
Investors
Document background
The General Contractor Contract is a fundamental document for construction projects in Qatar, essential for establishing the legal and operational framework between project owners and contractors. This document is typically used for medium to large-scale construction projects where a main contractor is responsible for overall project delivery. It incorporates requirements from Qatar's Civil Code, Construction Laws, and relevant regulations, while addressing key aspects such as scope definition, payment terms, project timeline, quality standards, and risk allocation. The contract is structured to comply with Qatar's legal framework while incorporating international construction industry best practices, making it suitable for both local and international contractors operating in Qatar. It includes comprehensive provisions for project management, dispute resolution, and regulatory compliance, particularly important given Qatar's rapid development and sophisticated construction market.
Suggested Sections

1. Parties: Identification and details of the contracting parties, including the Employer and the Contractor

2. Background: Context of the agreement and general purpose of the construction project

3. Definitions and Interpretation: Key terms used throughout the contract and rules for contract interpretation

4. Scope of Works: Detailed description of the construction works to be performed by the Contractor

5. Contract Price and Payment Terms: Contract sum, payment schedule, and mechanisms for payment

6. Project Timeline: Commencement date, completion date, and key milestone dates

7. Contractor's Obligations: Primary responsibilities and duties of the Contractor

8. Employer's Obligations: Primary responsibilities and duties of the Employer

9. Quality and Standards: Required quality standards, inspections, and approval processes

10. Variations: Procedures for handling changes to the scope of work

11. Health and Safety: Safety requirements and responsibilities on site

12. Insurance and Indemnities: Required insurance coverage and indemnification obligations

13. Defects Liability: Defects notification period and remediation procedures

14. Force Majeure: Events beyond parties' control and their consequences

15. Suspension and Termination: Rights and procedures for suspension and termination of the contract

16. Dispute Resolution: Procedures for resolving disputes, including arbitration provisions

17. Governing Law: Confirmation of Qatar law as governing law and jurisdiction

Optional Sections

1. Performance Security: Requirements for performance bonds or guarantees, used for high-value projects

2. Advance Payment: Terms for advance payments and their security, included when advance payments are required

3. Liquidated Damages: Pre-agreed damages for delay or performance failures, used in time-critical projects

4. Environmental Requirements: Specific environmental obligations, included for projects with significant environmental impact

5. Local Content Requirements: Requirements for local content and Qatarization, used in government or semi-government projects

6. Intellectual Property Rights: IP ownership and licenses, included when design or technology transfer is involved

7. Confidentiality: Confidentiality obligations, important for sensitive or high-profile projects

8. Step-In Rights: Employer's right to step in and complete works, used in critical infrastructure projects

Suggested Schedules

1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings

2. Schedule 2 - Project Program: Detailed timeline and milestone dates

3. Schedule 3 - Price Schedule: Detailed breakdown of contract price and bill of quantities

4. Schedule 4 - Payment Schedule: Payment milestones and procedures

5. Schedule 5 - Key Personnel: List of key personnel and their roles

6. Schedule 6 - Required Insurances: Details of required insurance policies

7. Schedule 7 - Site Information: Site details, access requirements, and existing conditions

8. Schedule 8 - Forms of Bonds and Guarantees: Templates for required bonds and guarantees

9. Schedule 9 - Quality Assurance Requirements: Detailed quality standards and testing requirements

10. Schedule 10 - HSE Requirements: Detailed health, safety, and environmental requirements

Authors

Alex Denne

Head of Growth (Open Source Law) @ ¶¶Òõ¶ÌÊÓƵ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co
Relevant legal definitions
































































Clauses
















































Relevant Industries

Construction

Real Estate Development

Infrastructure

Oil & Gas

Industrial

Commercial Development

Residential Development

Healthcare Facilities

Education Facilities

Hospitality

Transportation

Energy

Sports Facilities

Mixed-use Development

Relevant Teams

Legal

Commercial

Operations

Project Management

Procurement

Risk Management

Finance

Technical

Quality Assurance

Health Safety Environment

Construction

Contract Administration

Business Development

Executive Leadership

Relevant Roles

Project Director

Construction Manager

Contract Manager

Legal Counsel

Project Manager

Commercial Manager

Procurement Manager

Risk Manager

Chief Executive Officer

Operations Director

Technical Director

Finance Director

Quality Assurance Manager

HSE Manager

Site Manager

Quantity Surveyor

Cost Controller

Claims Manager

Industries










Teams

Employer, Employee, Start Date, Job Title, Department, Location, Probationary Period, Notice Period, Salary, Overtime, Vacation Pay, Statutory Holidays, Benefits, Bonus, Expenses, Working Hours, Rest Breaks,  Leaves of Absence, Confidentiality, Intellectual Property, Non-Solicitation, Non-Competition, Code of Conduct, Termination,  Severance Pay, Governing Law, Entire Agreemen

Find the exact document you need

Civil Contractor Agreement

A Qatar law-governed agreement between client and contractor for civil construction works, detailing project execution terms and regulatory compliance requirements.

find out more

Contractor Subcontractor Contract Agreement

A Qatar law-governed agreement between a main contractor and subcontractor defining works execution, payment terms, and compliance requirements for construction projects.

find out more

Agreement For Joint Venture In (Construction)

Qatar-law governed agreement establishing a joint venture partnership for construction projects, outlining operational, financial, and management framework while ensuring regulatory compliance.

find out more

Home Builder Agreement

Qatar-governed agreement between builder and property owner for residential construction, outlining construction terms, specifications, and compliance requirements.

find out more

Labor Contract For (Construction)

Qatar-compliant labor contract template for construction industry employment, incorporating local labor laws and construction-specific requirements.

find out more

Construction Payment Agreement

A Qatar law-governed agreement establishing payment terms and mechanisms between parties in a construction project.

find out more

Home Construction Contract

Qatar-governed contract for residential construction projects, outlining terms between property owner and contractor.

find out more

General Contractor Contract Agreement

Qatar-law governed construction contract between an employer and general contractor, setting out terms for project execution and parties' obligations.

find out more

Main Contractor And Subcontractor Agreement

A Qatar law-governed agreement between main contractor and subcontractor defining works scope, terms, and obligations for construction project execution.

find out more

Management Building Contract

Qatar-law governed management building contract for construction project oversight, incorporating local regulatory requirements and industry standards.

find out more

Construction Work Agreement

Qatar-law governed agreement setting out terms and conditions for construction works between an employer and contractor.

find out more

Subcontractor Letter Of Intent

A Qatar-law governed preliminary agreement between main contractor and subcontractor outlining intended subcontract terms and potential early works authorization.

find out more

New Construction Home Contract

Qatar-governed construction contract for new residential properties, defining builder and owner obligations under local construction law.

find out more

House Construction Agreement Between Owner Contractor

Qatar-law governed agreement between property owner and contractor for residential house construction, establishing terms, conditions, and obligations for the building project.

find out more

Construction Equipment Lease Agreement

Qatar-law governed agreement for construction equipment leasing, establishing terms between lessor and lessee with local regulatory compliance.

find out more

Construction Equipment Rental Agreement

Qatar-law governed agreement for construction equipment rental, establishing terms for equipment lease, operation, and maintenance.

find out more

Buyer Builder Agreement

A Qatar law-governed agreement between property owner and builder defining construction works, obligations, and terms for property development projects.

find out more

Construction Subcontract

Qatar law-governed agreement between main contractor and subcontractor for construction works execution, incorporating local regulatory requirements and industry standards.

find out more

Simple Construction Contract

A streamlined construction contract compliant with Qatar law, designed for straightforward construction projects.

find out more

General Contractor Contract

Qatar-compliant construction contract template establishing terms between project owners and general contractors, aligned with Qatar Civil Code and construction regulations.

find out more

General Contractor Agreement

A Qatar law-governed agreement between a principal and general contractor establishing terms for construction services and project delivery.

find out more

Building Contract Agreement

A Qatar law-governed construction contract establishing terms, obligations, and procedures for building works between an employer and contractor.

find out more

Download our whitepaper on the future of AI in Legal

By providing your email address you are consenting to our Privacy Notice.
Thank you for downloading our whitepaper. This should arrive in your inbox shortly. In the meantime, why not jump straight to a section that interests you here: /our-research
Oops! Something went wrong while submitting the form.

³Ò±ð²Ô¾±±ð’s Security Promise

Genie is the safest place to draft. Here’s how we prioritise your privacy and security.

Your documents are private:

We do not train on your data; ³Ò±ð²Ô¾±±ð’s AI improves independently

All data stored on Genie is private to your organisation

Your documents are protected:

Your documents are protected by ultra-secure 256-bit encryption

Our bank-grade security infrastructure undergoes regular external audits

We are ISO27001 certified, so your data is secure

Organizational security

You retain IP ownership of your documents

You have full control over your data and who gets to see it

Innovation in privacy:

Genie partnered with the Computational Privacy Department at Imperial College London

Together, we ran a £1 million research project on privacy and anonymity in legal contracts

Want to know more?

Visit our for more details and real-time security updates.

Read our Privacy Policy.