The Roofing Contract Agreement is a vital legal document used in the Philippines construction industry to formalize the relationship between a roofing contractor and property owner or developer. This agreement is essential when undertaking any significant roofing work, whether for new construction or renovation projects. The document ensures compliance with Philippine construction laws, including the National Building Code, Civil Code provisions on contracts, and CIAP regulations. It typically includes detailed specifications for materials and workmanship, project timelines, payment terms, warranties, and safety requirements. The agreement protects both parties by clearly defining responsibilities, quality standards, and dispute resolution procedures, while ensuring adherence to local building regulations and industry standards.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the Contractor and the Client/Property Owner, including complete legal names, addresses, and contact information
2. Background: Brief context of the agreement and the purpose of the roofing work
3. Definitions: Definitions of key terms used throughout the contract
4. Scope of Work: Detailed description of the roofing services to be provided, including specific tasks, materials, and area to be covered
5. Contract Price: Total cost of the project, payment schedule, and terms of payment
6. Timeline: Project schedule, including start date, completion date, and any specific milestones
7. Materials and Specifications: Detailed specifications of all materials to be used in the roofing work
8. Warranties and Guarantees: Specific warranties for workmanship and materials, including duration and coverage
9. Contractor's Obligations: Detailed responsibilities of the contractor, including safety measures, permits, and compliance with regulations
10. Client's Obligations: Responsibilities of the client, including site access, utilities provision, and payment obligations
11. Insurance and Liability: Insurance requirements and allocation of risks between parties
12. Termination: Conditions and procedures for contract termination by either party
13. Dispute Resolution: Procedures for handling disputes, including mediation and arbitration provisions
14. Governing Law: Specification of Philippine law as governing law and jurisdiction
15. Execution: Signature blocks and execution details
1. Force Majeure: Provisions for unforeseen circumstances or events beyond parties' control, particularly relevant in areas prone to extreme weather
2. Subcontracting: Terms and conditions for subcontracting work, if permitted
3. Environmental Compliance: Specific environmental requirements and certifications, particularly for green building projects
4. Variations and Changes: Procedures for handling changes to the scope of work or specifications
5. Liquidated Damages: Specific penalties for delays or breach of contract
6. Storage and Security: Provisions for storing materials and securing the work site, particularly for larger projects
7. Quality Control: Specific quality control measures and inspection procedures
8. Intellectual Property: Protection of designs or specialized techniques, if applicable
1. Schedule A - Technical Specifications: Detailed technical specifications of the roofing system, including materials, dimensions, and installation requirements
2. Schedule B - Site Plan: Drawings and plans showing the roof area and specific work locations
3. Schedule C - Payment Schedule: Detailed breakdown of payment installments and milestones
4. Schedule D - Project Timeline: Detailed project schedule with specific milestones and deadlines
5. Schedule E - Safety Requirements: Specific safety protocols and requirements for the project
6. Appendix 1 - Material Specifications: Manufacturer specifications and warranty information for materials
7. Appendix 2 - Permits and Licenses: Copies of relevant permits, licenses, and certifications
8. Appendix 3 - Insurance Certificates: Copies of required insurance policies and certificates
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate
Property Development
Facilities Management
Building Maintenance
Industrial Construction
Residential Construction
Commercial Construction
Property Management
Infrastructure Development
Relevant Teams
Legal
Procurement
Facilities Management
Project Management
Construction Management
Property Management
Contract Administration
Quality Assurance
Health and Safety
Technical Services
Operations
Risk Management
Relevant Roles
Construction Manager
Project Manager
Facilities Manager
Property Manager
Contracts Administrator
Legal Counsel
Construction Site Supervisor
Building Inspector
Quantity Surveyor
Procurement Manager
Real Estate Developer
Building Maintenance Manager
Roofing Contractor
General Contractor
Construction Safety Officer
Quality Control Manager
Find the exact document you need
Agreement Between Builder And Labour Contractor
A Philippine-law governed agreement between a Builder and Labour Contractor establishing terms for construction workforce services, including responsibilities, payments, and compliance requirements.
Download
Contract Between Employer And Contractor
A Philippine law-governed agreement establishing terms and conditions between an employer and contractor, defining scope of work, payments, and legal obligations.
Download
Agreement With Builder For (Construction)
A Philippine law-governed agreement between property owner and builder setting terms for construction works, including scope, payments, and compliance requirements.
Download
Independent Contractor Therapist Agreement
A Philippine law-governed agreement establishing the professional relationship between a healthcare facility and an independent contractor therapist, outlining service terms and compliance requirements.
Download
Contractor To Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between two independent contractors for business collaboration and service provision.
Download
Freelance Independent Contractor Agreement
A Philippine law-governed agreement establishing the terms and conditions between a client and an independent contractor, defining services, payments, and legal obligations.
Download
Contractor Agreement For House (Construction)
A Philippine law-governed agreement between property owner and contractor for residential house construction, outlining construction terms, specifications, and obligations.
Download
Contractor Work Contract
Philippine-law governed agreement establishing and regulating independent contractor relationships, defining work scope, terms, and obligations.
Download
Developer Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a client and software developer contractor, ensuring clear independent contractor status and protecting both parties' interests.
Download
Standard Renovation Contract
A comprehensive renovation agreement for use in the Philippines, establishing terms between property owners and contractors while ensuring compliance with Philippine construction laws.
Download
Agreement Between Owner And Electrical Contractor
A Philippine law-governed agreement between property owners and electrical contractors for electrical works, compliant with national electrical and construction regulations.
Download
Contractor Lease Agreement
A specialized lease agreement for contractors operating in the Philippines, combining property rental terms with construction-specific provisions under Philippine law.
Download
House Building Contract Agreement
A Philippine law-governed contract between property owner and contractor for residential house construction, detailing construction terms, payments, and obligations.
Download
Generic Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a client and independent contractor, ensuring legal compliance and clear relationship definition.
Download
Independent Service Contract
A Philippine law-governed agreement establishing terms and conditions between a client and independent contractor for professional services provision.
Download
Professional Services Subcontractor Agreement
A Philippine law-governed agreement between a contractor and subcontractor for professional services delivery, defining service scope, terms, and compliance requirements.
Download
Standard Employment Contract Form
A comprehensive employment contract template compliant with Philippine labor laws, establishing terms and conditions of employment between employer and employee.
Download
Short Form Contractor Agreement
A streamlined contractor agreement under Philippine law that establishes the terms of engagement between a company and an independent contractor.
Download
House Renovation Contract
A Philippine-law governed contract for residential renovation works, establishing terms between homeowner and contractor including scope, payments, and quality standards.
Download
Subcontractor Employment Agreement
A Philippine-compliant agreement establishing terms and conditions for subcontractor employment relationships, aligned with local labor laws and DOLE regulations.
Download
Painting Contract Agreement
A Philippine law-governed agreement establishing terms and conditions between a painting contractor and client for painting services.
Download
Driver Contractor Agreement
A Philippine law-governed agreement establishing terms between a company and an independent driver contractor, defining service conditions and operational requirements.
Download
Contractor Service Agreement
A Philippine law-governed agreement establishing terms and conditions between a client and independent contractor, defining service scope, payment terms, and contractor status.
Download
Consulting Agreement Contract
A Philippine law-governed agreement establishing terms and conditions between a client and consultant for professional consulting services.
Download
Standard Builders Contract
A Philippine law-governed construction agreement between owner and contractor, establishing terms for construction works while ensuring compliance with local regulations.
Download
Simple Engineering Contract
A standardized engineering contract template for Philippines-based projects, incorporating local legal requirements and engineering standards.
Download
Simple Handyman Contract
A Philippine law-compliant contract establishing terms between a handyman and property owner for maintenance or repair services.
Download
Salon Contract For Employees
A Philippine-compliant employment agreement for salon industry workers, establishing terms, conditions, and professional standards for salon employment relationships.
Download
Preferred Contractor Agreement
A Philippine law-governed agreement establishing a preferred independent contractor relationship, defining service terms and maintaining contractor independence while ensuring legal compliance.
Download
Percentage Agreement Contract
A Philippine law-governed agreement establishing percentage-based payment terms and conditions between contracting parties for revenue sharing, commissions, or profit-sharing arrangements.
Download
Painting Subcontractor Contract
A Philippine law-governed agreement between a main contractor and painting subcontractor defining terms for painting works execution, including quality standards and payment terms.
Download
Part Time Contractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a company and a part-time independent contractor.
Download
Non Profit Contractor Agreement
A Philippine law-governed agreement between a non-profit organization and an independent contractor, defining their working relationship and mutual obligations.
Download
Independent Employment Agreement
A Philippine law-governed agreement establishing terms between a company and independent contractor, ensuring legal compliance while protecting both parties' interests.
Download
General Contract Agreement Between Two Parties
A general contract agreement template compliant with Philippine law, designed for establishing legally binding agreements between two parties.
Download
Fence Contract Agreement
A legally binding agreement under Philippine law that governs the terms and conditions for fence construction or installation between a property owner and contractor.
Download
Contract Agreement For Interior Works
A Philippine law-governed agreement establishing terms and conditions for interior construction and renovation works between contracting parties.
Download
Construction Service Contract
A Philippine law-governed agreement establishing terms and conditions between an owner and contractor for construction services, incorporating local construction and safety regulations.
Download
Carpenter Contract Agreement
A Philippine-law governed agreement establishing terms and conditions between a carpenter and client for carpentry services, ensuring compliance with local labor and construction regulations.
Download
Basic Simple Subcontractor Agreement
A Philippine law-governed agreement establishing terms and conditions between a main contractor and subcontractor for delegated work or services.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)