Construction Service Agreement

Construction Service Agreement Template for Malaysia

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Construction Service Agreement

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

"I need a Construction Service Agreement for a 20-story commercial building project in Kuala Lumpur, Malaysia, with construction scheduled to begin in March 2025, ensuring compliance with current Malaysian green building standards and CIDB requirements."

Document background

The Construction Service Agreement is a fundamental document used in the Malaysian construction industry to establish a legally binding relationship between a client/employer and a contractor for construction projects. This agreement is essential for any construction project in Malaysia, whether commercial, residential, or infrastructure-related, and must comply with local regulations including the Construction Industry Development Board Act 1994 and related legislation. The document typically includes detailed provisions for scope of works, payment terms, project timelines, quality standards, safety requirements, and dispute resolution mechanisms. It is designed to protect both parties' interests while ensuring project delivery meets Malaysian construction standards and regulatory requirements. The agreement should be customized based on project size, complexity, and specific requirements while maintaining compliance with Malaysian law.

Suggested Sections

1. Parties: Identification of the contracting parties - typically the employer/client and the contractor, including registration details and addresses

2. Background: Context of the agreement, brief project overview, and basis for the construction services

3. Definitions and Interpretation: Detailed definitions of terms used throughout the agreement and rules of interpretation

4. Scope of Works: Detailed description of construction services to be performed, including general and specific obligations

5. Contract Price and Payment Terms: Agreement on pricing, payment schedule, variations, and payment procedures

6. Project Timeline: Construction schedule, milestones, completion dates, and provisions for extensions of time

7. Contractor's Obligations: Detailed responsibilities including workmanship, materials, compliance with laws and standards

8. Client's Obligations: Client's responsibilities including site access, permits, approvals, and information provision

9. Quality and Standards: Required quality standards, inspections, testing procedures, and acceptance criteria

10. Health, Safety and Environment: HSE requirements, compliance with regulations, and safety management procedures

11. Variations: Procedures for handling changes to scope, pricing, or timeline

12. Insurance and Indemnities: Required insurance coverage and indemnification obligations

13. Default and Termination: Events of default, remedies, and termination procedures

14. Force Majeure: Provisions for unforeseen circumstances and their handling

15. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration processes

16. General Provisions: Standard legal provisions including notices, governing law, and entire agreement

Optional Sections

1. Performance Bond: Required for larger projects or when client requires additional security

2. Retention Sum: Specific provisions for retention money, typically used in larger projects

3. Intellectual Property Rights: Include when design services or proprietary methods are involved

4. Confidentiality: Required when sensitive information or proprietary methods are involved

5. Environmental Management: Detailed section for projects with significant environmental impact

6. Local Content Requirements: Include when project must meet specific local content or bumiputera participation requirements

7. Defects Liability Period: Detailed provisions for post-completion defects liability, typically for larger projects

8. Warranties: Specific warranties beyond standard contractor obligations

9. Step-in Rights: Include for critical projects where client may need to take over

10. Subcontracting: Detailed provisions when subcontracting is expected to be significant

Suggested Schedules

1. Schedule 1 - Scope of Works: Detailed technical specifications and drawings

2. Schedule 2 - Project Timeline: Detailed construction schedule with milestones

3. Schedule 3 - Contract Price Breakdown: Detailed breakdown of costs and bill of quantities

4. Schedule 4 - Payment Schedule: Detailed payment terms and milestone payments

5. Schedule 5 - Site Details: Site information, access points, and conditions

6. Schedule 6 - Required Insurances: Details of all required insurance policies

7. Schedule 7 - Key Personnel: List of key personnel from both parties

8. Schedule 8 - Forms and Procedures: Standard forms for variations, claims, and certificates

9. Schedule 9 - Technical Standards: Applicable technical standards and specifications

10. Schedule 10 - Permits and Approvals: List of required permits and responsible parties

Authors

Alex Denne

Head of Growth (Open Source Law) @ ��Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Real Estate

Construction

Infrastructure

Commercial Property

Residential Property

Industrial Development

Healthcare Facilities

Education Facilities

Hospitality

Retail Development

Transportation

Energy and Utilities

Relevant Teams

Legal

Operations

Project Management

Procurement

Finance

Risk Management

Compliance

Construction

Commercial

Technical Services

Development

Health and Safety

Relevant Roles

CEO

Project Manager

Construction Manager

Contract Manager

Legal Counsel

Chief Legal Officer

Procurement Manager

Risk Manager

Financial Controller

Chief Financial Officer

Operations Director

Development Director

Technical Director

Site Manager

Quantity Surveyor

Commercial Manager

Compliance Officer

Health and Safety Manager

Project Engineer

Architect

Find the exact document you need

Agreement And Conditions Of Contract For Building Works

A Malaysian law-governed construction contract template establishing terms and conditions for building works projects.

��������Ƶ

How ��������Ƶ reduced drafting time by 75% for a legal firm

Let's create your Construction Service Agreement

Authors

Alex Denne

Find the exact document you need

Agreement And Conditions Of Contract For Building Works

Construction Payment Agreement

Construction Framework Agreement

Service Level Agreement For Construction Works

General Contractor Contract With Subcontractor

Contractor Warranty Agreement

Residential Construction Agreement

Construction Collaboration Agreement

Agreement Between Land Owner And Builder

Management Building Contract

Construction Work Agreement

General Contractor Contract With Owner

Construction Labor Agreement

Builder Development Agreement

Residential Construction Contract

Construction Payment Contract

Construction Lease Agreement

Construction Equipment Lease Agreement

Construction Service Agreement

Construction Equipment Rental Agreement

New Construction Agreement

Buyer Builder Agreement

Construction Subcontract

Construction Management Agreement

Pre Construction Agreement

Construction Management Contract

Cost Plus Construction Agreement

Download our whitepaper on the future of AI in Legal

�ұ�Ծ���’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy:

Want to know more?

Use Cases

��Ƶ

How ��Ƶ reduced drafting time by 75% for a legal firm

�ұ�Ծ��’s Security Promise