The Commercial Construction Agreement is a crucial legal document used in India when engaging contractors for commercial building projects. It serves as the primary contract between property owners/developers and construction contractors, establishing their rights, obligations, and responsibilities throughout the construction process. This agreement is essential for projects such as office buildings, retail spaces, industrial facilities, and other commercial structures, ensuring compliance with Indian construction laws, including the Real Estate (Regulation and Development) Act, 2016, and various state-specific building codes. The document typically incorporates provisions for project timelines, payment structures, quality standards, safety requirements, and dispute resolution mechanisms, while addressing specific Indian regulatory requirements such as labor laws, environmental regulations, and local building bylaws.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Details of the Owner/Employer and the Contractor, including their registered addresses and company registration numbers
2. Background: Context of the agreement, including brief project overview and basis for entering into the contract
3. Definitions and Interpretation: Definitions of key terms used throughout the agreement and rules for interpreting the contract
4. Scope of Work: Detailed description of the construction work to be performed, including general obligations of the contractor
5. Contract Price and Payment Terms: Agreement on price, payment schedule, retention money, and payment procedures
6. Project Timeline: Construction schedule, completion dates, milestones, and provisions for extensions of time
7. Contractor's Obligations: Specific responsibilities including labor, materials, equipment, safety measures, and compliance requirements
8. Owner's Obligations: Responsibilities of the owner including site access, approvals, and permits
9. Quality Control and Inspection: Standards for materials and workmanship, inspection procedures, and quality assurance requirements
10. Variations and Changes: Procedures for handling changes to scope, specifications, or other contract terms
11. Insurance and Indemnity: Required insurance coverage and indemnification obligations of both parties
12. Defects Liability: Warranty period, remediation of defects, and maintenance obligations
13. Force Majeure: Provisions for handling unforeseen circumstances and their impact on contract performance
14. Termination: Grounds and procedures for contract termination by either party
15. Dispute Resolution: Procedures for resolving disputes, including mediation, arbitration, and jurisdiction
16. Governing Law: Specification of Indian law as governing law and relevant jurisdiction
17. General Provisions: Standard clauses including notices, amendments, entire agreement, and severability
1. Environmental Compliance: Detailed environmental obligations when project requires specific environmental clearances or has significant environmental impact
2. Labor Housing and Welfare: Requirements for worker accommodation and welfare when project involves large workforce or remote location
3. Intellectual Property Rights: IP provisions when project involves unique designs or proprietary construction methods
4. Security Requirements: Special security measures when construction is in sensitive areas or involves critical infrastructure
5. Local Content Requirements: Provisions for local material/labor usage when required by local regulations or project specifications
6. Liquidated Damages: Specific compensation amounts for delay or non-performance when project has critical completion requirements
7. Step-in Rights: Owner's rights to take over work when project is critical and risk of contractor default exists
8. Anti-corruption Compliance: Detailed anti-corruption provisions for government projects or when required by stakeholders
1. Schedule A - Technical Specifications: Detailed technical requirements, drawings, and construction specifications
2. Schedule B - Bill of Quantities: Itemized list of materials, works, and their quantities with prices
3. Schedule C - Project Timeline: Detailed project schedule with milestones and completion dates
4. Schedule D - Payment Schedule: Detailed breakdown of payment terms, installments, and milestone payments
5. Schedule E - Site Plan and Access Details: Site layout, access points, and temporary works locations
6. Schedule F - Quality Assurance Plan: Detailed quality control procedures and acceptance criteria
7. Schedule G - Required Permits and Approvals: List of necessary permits and responsibilities for obtaining them
8. Schedule H - Insurance Requirements: Detailed insurance coverage requirements and minimum coverage amounts
9. Appendix 1 - Forms and Certificates: Standard forms for site instructions, completion certificates, and payment applications
10. Appendix 2 - Safety Manual: Site safety procedures and requirements
Relevant legal definitions
Clauses
Relevant Industries
Real Estate
Construction
Infrastructure
Commercial Property Development
Industrial Manufacturing
Retail
Hospitality
Healthcare
Education
Technology Parks
Warehousing and Logistics
Banking and Financial Services
Relevant Teams
Legal
Construction
Project Management
Finance
Procurement
Operations
Risk and Compliance
Property Development
Technical Services
Commercial Operations
Facilities Management
Contract Administration
Relevant Roles
Chief Executive Officer
Managing Director
Construction Project Manager
Contract Manager
Legal Counsel
Chief Financial Officer
Procurement Manager
Site Engineer
Quantity Surveyor
Risk Manager
Compliance Officer
Property Developer
Construction Manager
Facilities Manager
Operations Director
Technical Director
Commercial Director
Development Manager
Find the exact document you need
Material Supply Contract In (Construction)
An Indian law-governed agreement establishing terms for construction material supply, including specifications, quality standards, delivery terms, and regulatory compliance requirements.
Download
Land Owner Builder Agreement
An Indian law-governed agreement between landowner and builder/developer establishing terms for property development and construction.
Download
Labor Contract For (Construction)
An Indian-law compliant labor contract for construction workers, establishing employment terms and conditions while ensuring compliance with Indian construction industry regulations.
Download
Joint Development Agreement For (Construction)
An Indian law-governed agreement establishing terms between landowner and developer for joint construction project development, including rights, obligations, and profit-sharing arrangements.
Download
Home Renovation Contractor Agreement
An Indian law-governed agreement between property owners and contractors for home renovation projects, detailing work scope, terms, and obligations.
Download
Cost Plus Residential Construction Contract
An Indian law-governed construction contract establishing cost-plus pricing terms for residential building projects, with contractor compensation based on actual costs plus agreed markup.
Download
Contractor Agreement For House (Construction)
An Indian law-governed agreement between property owner and contractor for house construction, detailing construction terms, specifications, and compliance requirements.
Download
Building Contract And Consultancy Agreement For A Home Owner Occupier
An Indian law-governed agreement between a home owner-occupier and construction/consultancy providers for residential property construction and related services.
Download
Third Party Agreement (Construction)
An Indian law-governed agreement between principal contractor and subcontractor for construction works, establishing their rights and obligations.
Download
Tripartite Agreement In (Construction)
An Indian law-governed agreement establishing rights and obligations between three parties in a construction project, typically involving developer, contractor, and financier/buyer.
Download
Standard General Contractor Contract
An Indian law-governed construction agreement between project owner and general contractor defining terms, obligations, and requirements for construction project execution.
Download
Residential Construction Management Agreement
An Indian law-compliant agreement between property owner and construction manager for managing residential construction projects, incorporating RERA and local building regulations.
Download
Simple Works Contract
An Indian law-governed contract between an employer and contractor for executing specified construction or physical works, incorporating essential legal and practical requirements.
Download
Project Management Contract In (Construction)
A Project Management Contract for construction projects in India, establishing terms for project management services under Indian law.
Download
Project Management Agreement (Construction)
An Indian law-governed agreement defining terms for professional project management services in construction projects, including scope, responsibilities, and compliance requirements.
Download
Joint Venture Agreement For (Construction)
An Indian law-governed agreement establishing a joint venture between parties for construction projects, detailing operational, financial, and management arrangements.
Download
Independent Contractor Agreement For (Construction)
An Indian law-compliant agreement governing the relationship between a hiring entity and an independent contractor for construction services.
Download
Generic Construction Contract
Standard construction contract template compliant with Indian law, suitable for various construction projects in India.
Download
Construction Payment Agreement
An Indian law-governed agreement establishing payment terms and procedures for construction projects, including payment milestones, documentation requirements, and dispute resolution mechanisms.
Download
Construction Agreement And Sale Agreement
An Indian law-governed agreement combining construction specifications and property sale terms, compliant with RERA and related legislation.
Download
Contract Between Contractor And Owner
An Indian law-governed agreement between property owner and construction contractor defining construction terms, obligations, and project execution requirements.
Download
Standard Contractor Contract
An Indian law-governed agreement establishing and regulating the relationship between a company and an independent contractor, defining key terms and obligations.
Download
Simple Contract Agreement For Construction Work
A standard construction agreement under Indian law defining terms between client and contractor for construction works.
Download
Construction Agreement Letter
An Indian jurisdiction document establishing terms between property owner/developer and contractor for construction projects, governed by Indian contract law.
Download
Standard Building Contract
An Indian law-governed agreement between property owners/developers and contractors establishing terms for construction projects.
Download
Real Estate Construction Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction services, including scope, payments, and regulatory compliance.
Download
Construction Warranty Agreement
An Indian law-governed agreement establishing construction warranty terms between builders and property owners, detailing coverage, claims procedures, and remedies for construction defects.
Download
Contract Between Builder And Subcontractor
An Indian law-governed agreement between a builder and subcontractor for construction works, detailing scope, terms, and compliance requirements.
Download
Construction Completion Agreement
An Indian law-governed agreement that establishes terms and conditions for completing an ongoing construction project, ensuring compliance with local construction regulations and RERA.
Download
Residential Construction Management Contract
An Indian law-compliant agreement for managing residential construction projects, establishing terms between property owners and construction managers.
Download
Simple Work For Hire Agreement
An Indian law-governed agreement establishing a work-for-hire relationship between a client and contractor, defining work scope and IP rights transfer.
Download
Agreement Between Builder And Contractor
An Indian law-governed agreement between builder and contractor defining construction project terms, obligations, and deliverables.
Download
Landscape Contractor Contract
An Indian law-governed contract between a client and landscape contractor establishing terms for landscaping works, including scope, payments, and compliance requirements.
Download
Contract Between Builder And Client
An Indian law-governed construction agreement between a builder and client, outlining project terms, specifications, and mutual obligations.
Download
Agreement Between Two Contractors
An Indian law-governed agreement establishing terms and conditions between two independent contractors for professional collaboration and service delivery.
Download
Swimming Pool Construction Agreement
An Indian law-governed agreement for swimming pool construction, detailing contractor and owner obligations, specifications, and compliance requirements.
Download
Standard Construction Agreement
An Indian law-governed agreement between owner and contractor establishing terms and conditions for construction projects.
Download
Owner Builder Subcontractor Agreement
An Indian law-compliant agreement between an owner-builder and subcontractor for construction works, detailing work scope, payments, and compliance requirements.
Download
Construction Labor Contract Agreement
An Indian law-governed agreement establishing terms for construction labor supply and management, ensuring compliance with relevant labor laws and regulations.
Download
Construction Collaboration Agreement
An agreement governing construction collaboration between multiple parties in India, outlining project terms, responsibilities, and compliance with Indian construction laws.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)