Standard General Contractor Contract

Standard General Contractor Contract Template for India

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Standard General Contractor Contract

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

"I need a Standard General Contractor Contract for a luxury hotel construction project in Mumbai with a value of INR 150 crore, starting March 2025, with specific provisions for sustainable building practices and LEED certification requirements."

Document background

The Standard General Contractor Contract is a fundamental document used in the Indian construction industry to establish a legally binding agreement between project owners and general contractors. This contract type is essential for projects requiring professional construction services and is structured to comply with Indian contract law, construction regulations, and industry standards. It encompasses crucial elements such as scope definition, pricing, timelines, quality requirements, and risk allocation, while ensuring adherence to local building codes, labor laws, and safety regulations. The document is particularly relevant for medium to large-scale construction projects where professional project management and formal contractual relationships are required. It provides a comprehensive framework for project execution, including mechanisms for changes, dispute resolution, and project completion, while protecting the interests of all parties involved.

Suggested Sections

1. Parties: Identification of the Owner/Employer and the General Contractor, including their legal details and registered addresses

2. Background: Context of the agreement, brief project overview, and basis for entering into the contract

3. Definitions: Detailed definitions of terms used throughout the contract

4. Scope of Work: Detailed description of the construction work to be performed by the General Contractor

5. Contract Price and Payment Terms: Total contract value, payment schedule, milestone payments, and payment procedures

6. Project Timeline: Commencement date, completion date, project phases, and milestone deadlines

7. Contractor's Obligations: General Contractor's responsibilities, including quality standards, labor, materials, and supervision

8. Owner's Obligations: Owner's responsibilities including site access, approvals, and permits

9. Quality Standards: Required quality standards, inspections, and acceptance criteria

10. Safety Requirements: Safety protocols, compliance with laws, and accident prevention measures

11. Changes and Variations: Procedures for handling changes to scope, pricing, or timeline

12. Insurance and Indemnity: Required insurance coverage and indemnification obligations

13. Default and Termination: Events of default, remedies, and termination procedures

14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

15. Force Majeure: Provisions for handling unforeseen circumstances and their impact

16. Governing Law: Specification of Indian law as governing law and jurisdiction

17. Notices: Process and addresses for serving formal notices

18. General Provisions: Standard boilerplate clauses including assignment, waiver, and severability

Optional Sections

1. Subcontracting: Rules and procedures for subcontracting work - include when subcontractors are expected to be used

2. Environmental Compliance: Specific environmental obligations - include for projects with significant environmental impact

3. Labor Compliance: Detailed labor law compliance requirements - include for large projects with significant workforce

4. Intellectual Property Rights: IP ownership and licenses - include when design or technical innovations are involved

5. Performance Security: Requirements for performance bonds or guarantees - include for high-value projects

6. Warranty Period: Extended warranty terms - include for complex construction projects

7. Site Conditions: Specific site-related obligations and risks - include for projects with challenging site conditions

8. Materials Storage: Requirements for storage and security of materials - include for projects with significant material requirements

Suggested Schedules

1. Schedule A - Scope of Work: Detailed technical specifications and drawings of the project

2. Schedule B - Bill of Quantities: Detailed breakdown of quantities and rates for all work items

3. Schedule C - Project Timeline: Detailed project schedule with milestones and critical path

4. Schedule D - Payment Schedule: Detailed payment terms, milestone payments, and payment procedures

5. Schedule E - Quality Standards: Specific quality requirements, testing procedures, and acceptance criteria

6. Schedule F - Site Details: Site plan, access points, and site-specific requirements

7. Schedule G - List of Approved Subcontractors: Pre-approved subcontractors for specific work packages

8. Schedule H - Forms and Certificates: Standard forms for variations, completion certificates, and other project documents

9. Schedule I - Insurance Requirements: Detailed insurance coverage requirements and minimum values

10. Schedule J - Safety Requirements: Specific safety protocols and procedures

Authors

Alex Denne

Head of Growth (Open Source Law) @ ��Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Commercial Construction

Residential Construction

Industrial Construction

Infrastructure Development

Real Estate Development

Government Construction

Healthcare Construction

Educational Facilities

Retail Construction

Hospitality Construction

Manufacturing Facilities

Transportation Infrastructure

Relevant Teams

Legal

Operations

Construction

Project Management

Commercial

Procurement

Finance

Risk Management

Quality Control

Health and Safety

Technical Services

Business Development

Contract Administration

Relevant Roles

Project Manager

Construction Manager

Contract Administrator

Legal Counsel

Quantity Surveyor

Site Supervisor

Procurement Manager

Chief Engineer

Operations Director

Risk Manager

Commercial Manager

Business Development Manager

Managing Director

CEO

CFO

Technical Director

Quality Control Manager

Health and Safety Manager

Find the exact document you need

Material Supply Contract In (Construction)

An Indian law-governed agreement establishing terms for construction material supply, including specifications, quality standards, delivery terms, and regulatory compliance requirements.

��������Ƶ

How a Sales & Marketing Lead uses ��������Ƶ to reduce contract drafting time by 95%

Let's create your Standard General Contractor Contract

Authors

Alex Denne

Find the exact document you need

Material Supply Contract In (Construction)

Land Owner Builder Agreement

Labor Contract For (Construction)

Joint Development Agreement For (Construction)

Home Renovation Contractor Agreement

Cost Plus Residential Construction Contract

Contractor Agreement For House (Construction)

Building Contract And Consultancy Agreement For A Home Owner Occupier

Third Party Agreement (Construction)

Tripartite Agreement In (Construction)

Standard General Contractor Contract

Residential Construction Management Agreement

Simple Works Contract

Project Management Contract In (Construction)

Project Management Agreement (Construction)

Joint Venture Agreement For (Construction)

Independent Contractor Agreement For (Construction)

Generic Construction Contract

Construction Payment Agreement

Construction Agreement And Sale Agreement

Contract Between Contractor And Owner

Standard Contractor Contract

Construction Agreement Letter

Standard Building Contract

Real Estate Construction Contract

Construction Warranty Agreement

Contract Between Builder And Subcontractor

Construction Completion Agreement

Residential Construction Management Contract

Agreement Between Builder And Contractor

Landscape Contractor Contract

Contract Between Builder And Client

Agreement Between Two Contractors

Swimming Pool Construction Agreement

Standard Construction Agreement

Owner Builder Subcontractor Agreement

Construction Labor Contract Agreement

Construction Collaboration Agreement

Commercial Construction Agreement

General Contractor Contract With Owner

Construction Labor Agreement

Builder Development Agreement

Construction Payment Contract

Construction Lease Agreement

Contract For Contractor And Homeowner

Construction Equipment Lease Agreement

Basic Building Contract

Construction Work Order Agreement

Construction Project Agreement

Road Construction Agreement

Engineering Procurement And Construction Agreement

Construction Equipment Rental Agreement

Building Maintenance Agreement

Buyer Builder Agreement

Construction Partnership Agreement

Construction Employee Contract

Supply And Installation Agreement

Construction Subcontract

Construction Management Agreement

Remodeling Contractor Agreement

General Construction Agreement

Construction Management Contract

Cost Plus Construction Agreement

Access Agreement For (Construction)

Download our whitepaper on the future of AI in Legal

�ұ�Ծ���’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security

Innovation in privacy:

Want to know more?

Use Cases

��Ƶ

How a Sales & Marketing Lead uses ��Ƶ to reduce contract drafting time by 95%

�ұ�Ծ��’s Security Promise