The House Building Contractor Agreement serves as the primary contractual document between property owners and construction contractors in Indonesia for residential building projects. This agreement is essential when engaging a contractor for new house construction, major renovations, or rebuilding projects. It incorporates crucial elements required under Indonesian law, including compliance with Law No. 2 of 2017 on Construction Services and Law No. 28 of 2002 on Buildings. The document outlines detailed specifications, construction timelines, payment schedules, quality standards, and dispute resolution procedures. It's designed to protect both parties' interests while ensuring adherence to local building codes, permit requirements, and safety regulations. The agreement is particularly important in the Indonesian context where construction practices must align with specific regional building regulations (Perda) and environmental requirements.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification of the property owner (employer) and the building contractor, including their complete legal names, addresses, and registration details
2. Background: Brief context of the agreement, including the owner's intention to build and the contractor's qualifications and licenses
3. Definitions: Definitions of key terms used throughout the agreement, including technical construction terms and contract-specific definitions
4. Scope of Work: Detailed description of the construction work to be performed, including general specifications and references to detailed plans
5. Contract Price and Payment Terms: Total contract value, payment schedule, payment methods, and conditions for payment
6. Timeline and Completion: Project schedule, completion date, mechanisms for extensions, and definitions of practical completion
7. Contractor's Obligations: Key responsibilities including quality standards, compliance with laws, safety measures, and site management
8. Owner's Obligations: Responsibilities of the property owner including site access, permits, and timely provision of information
9. Materials and Workmanship: Standards for materials, procurement requirements, and quality control processes
10. Variations: Procedures for handling changes to scope, pricing of variations, and approval process
11. Insurance and Indemnity: Required insurance coverage and indemnification obligations of both parties
12. Defects Liability: Defects liability period, remediation process, and warranties
13. Termination: Grounds for termination, termination process, and consequences
14. Force Majeure: Definition of force majeure events and their impact on contractual obligations
15. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures
16. Governing Law: Specification of Indonesian law as governing law and jurisdiction
1. Site Conditions: Specific provisions relating to known site conditions, soil reports, and risk allocation - include when building on challenging terrain or when specific site issues are known
2. Environmental Protection: Specific environmental management requirements - include when project has significant environmental impacts or is in environmentally sensitive areas
3. Subordinate Contractors: Provisions for managing other contractors on site - include when multiple contractors will be working simultaneously
4. Acceleration: Provisions for accelerating work and associated costs - include for time-critical projects
5. Performance Bond: Requirements for performance security - include for high-value projects or when required by financing
6. Intellectual Property: Protection of design rights and licenses - include when custom designs or innovative construction methods are involved
7. Local Community Relations: Requirements for managing community impact - include in densely populated areas or sensitive locations
1. Schedule 1 - Construction Drawings and Specifications: Detailed architectural and engineering drawings, technical specifications
2. Schedule 2 - Bill of Quantities: Itemized list of materials, quantities, and prices
3. Schedule 3 - Construction Timeline: Detailed project schedule including milestones and critical path
4. Schedule 4 - Payment Schedule: Detailed breakdown of payment installments and milestone payments
5. Schedule 5 - Required Permits and Approvals: List of all required regulatory approvals and responsible parties
6. Schedule 6 - Quality Control Plan: Detailed quality assurance and control procedures
7. Schedule 7 - Site Safety Plan: Safety procedures and protocols for the construction site
8. Schedule 8 - Insurance Requirements: Detailed insurance specifications and coverage requirements
9. Appendix A - Forms and Certificates: Standard forms for variations, completion certificates, and other project documents
10. Appendix B - Key Personnel: List of key project personnel and their responsibilities
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate
Architecture
Engineering
Property Development
Building Materials
Construction Management
Residential Development
Relevant Teams
Legal
Construction
Project Management
Procurement
Risk and Compliance
Property Development
Technical Services
Contract Administration
Quality Assurance
Operations
Relevant Roles
Construction Manager
Project Manager
Contract Administrator
Legal Counsel
Property Developer
Architect
Quantity Surveyor
Site Engineer
Building Inspector
Compliance Officer
Construction Director
Procurement Manager
Risk Manager
Property Manager
Technical Director
Find the exact document you need
Build Agreement
An Indonesian law-governed construction contract establishing terms and conditions for building projects, compliant with local construction regulations and industry standards.
Download
Project Consortium Agreement
An Indonesian law-governed agreement establishing a consortium between multiple parties for collaborative project execution, defining rights, responsibilities, and operational framework.
Download
Project Labor Agreement
An Indonesian-law governed Project Labor Agreement establishing terms and conditions for construction project labor relations and workforce management.
Download
Project Management Agreement (Construction)
An Indonesian law-governed agreement for construction project management services, outlining service scope, responsibilities, and compliance requirements.
Download
Film Shopping Agreement
An Indonesian law-governed agreement authorizing an agent to market and present a film to potential buyers in specified territories, outlining rights, commission structures, and approval requirements.
Download
Subcontractor Work Order
An Indonesian law-governed agreement between a main contractor and subcontractor defining specific construction works, terms, and obligations within a larger project.
Download
Construction Contractor Agreement
An Indonesian law-governed agreement between project owner and contractor establishing terms for construction works execution.
Download
Project Financing Agreement
An Indonesian law-governed agreement establishing terms and conditions for project financing, including facility details, security package, and compliance with local banking and investment regulations.
Download
Mural Agreement
An Indonesian law-governed agreement for commissioning and executing mural artwork projects, addressing artistic, legal, and commercial aspects of mural creation.
Download
Home Construction Agreement
An Indonesian law-governed agreement between property owner and contractor for residential property construction, compliant with local construction and housing regulations.
Download
Project Based Employment Agreement
An Indonesian law-compliant employment agreement for project-based work arrangements (PKWT), defining project terms, conditions, and employment parameters.
Download
Pipeline Agreement
An agreement governing pipeline operations and transportation services in Indonesia, compliant with local oil and gas regulations.
Download
House Building Contractor Agreement
An Indonesian law-governed agreement between a property owner and contractor for residential house construction, establishing construction terms, specifications, and obligations.
Download
Freelance Project Contract
An Indonesian law-governed contract establishing terms and conditions for project-based freelance work, including scope, deliverables, and payment terms.
Download
IT Project Agreement
An Indonesian law-governed agreement for IT project implementation, detailing scope, deliverables, and compliance requirements.
Download
General Contractor Work Agreement
An Indonesian law-governed agreement between project owner and general contractor establishing terms for construction services delivery.
Download
Construction Operating Agreement
An Indonesian law-governed agreement establishing terms for facility construction and subsequent operation, combining construction and operational requirements under Indonesian construction services legislation.
Download
Mining Concession Agreement
An Indonesian law-governed agreement granting mining rights and establishing operational terms for mineral exploration and production activities.
Download
Consortium Partnership Agreement
An Indonesian law-governed agreement establishing a consortium partnership between multiple organizations, defining their rights, responsibilities, and operational framework.
Download
Engineering And Construction Subcontract
An Indonesian law-governed agreement between main contractor and subcontractor for specific engineering and construction works, complying with local construction regulations and standards.
Download
Business Consortium Agreement
An Indonesian law-governed agreement establishing a business consortium arrangement between multiple parties, defining their collaboration framework and mutual obligations.
Download
Operation And Maintenance Agreement Solar Power Plant
An Operation and Maintenance Agreement template for solar power plants, compliant with Indonesian law and regulations, covering comprehensive facility management and maintenance requirements.
Download
Subcontractor Work Agreement
An Indonesian law-governed agreement between a main contractor and subcontractor defining work scope, terms, and compliance requirements for delegated project work.
Download
Simple Construction Agreement
An Indonesian law-governed construction agreement establishing core terms between property owner and contractor for straightforward construction projects.
Download
Building Construction Agreement
An Indonesian law-governed agreement between property owner and contractor for building construction works, compliant with local construction regulations.
Download
Project Support Agreement
An Indonesian law-governed agreement defining the terms and conditions for providing project support services, including scope, responsibilities, and commercial terms.
Download
Project Management Agreement
An Indonesian law-governed agreement establishing terms for project management services, including scope, responsibilities, and deliverables.
Download
Project Alliance Agreement
An Indonesian law-governed collaborative agreement for complex project delivery, establishing shared risk-reward mechanisms and joint decision-making frameworks.
Download
Consortium Agreement Construction Project
Indonesian law-governed agreement establishing a construction consortium, defining member rights, obligations, and project execution framework.
Download
Project Profit Sharing Agreement
An Indonesian law-governed agreement establishing profit-sharing arrangements between parties for a specific project, including financial, operational, and management frameworks.
Download
Project Implementation Agreement
An Indonesian law-governed agreement establishing the framework for project implementation between project owners and contractors, detailing execution responsibilities and compliance requirements.
Download
Construction Lease Agreement
An Indonesian law-governed agreement combining property lease terms with construction rights and obligations, subject to local building and property regulations.
Download
Build Own Transfer Agreement
An Indonesian law-governed agreement structuring Build-Own-Transfer infrastructure projects, covering construction, operation, and facility transfer phases.
Download
Project Agreement Between Company And Client
An Indonesian law-governed agreement defining project terms, deliverables, and obligations between a service provider and client.
Download
Pilot Project Agreement
An Indonesian law-governed agreement establishing terms and conditions for implementing and evaluating a pilot project, including scope, responsibilities, and success criteria.
Download
Project Service Agreement
An Indonesian law-governed agreement for project-based service delivery, detailing scope, obligations, and terms between service provider and client.
Download
Construction Project Agreement
An Indonesian law-governed agreement establishing terms and conditions for construction projects, including scope, payments, and regulatory compliance requirements.
Download
Software Implementation Agreement
An Indonesian law-governed agreement for software implementation projects, detailing implementation terms, deliverables, and compliance requirements.
Download
Road Construction Agreement
An Indonesian law-governed agreement for road construction projects, outlining technical, financial, and legal requirements under Indonesian construction regulations.
Download
Project Funding Agreement
An Indonesian law-governed agreement that establishes terms and conditions for project funding between providers and recipients, including disbursement schedules and compliance requirements.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)