��������Ƶ

This Home Renovation Contract is designed for use in Malaysia when a property owner engages a contractor to perform residential renovation works. The document is structured to comply with Malaysian legislation, including the Contracts Act 1950, Consumer Protection Act 1999, and relevant building regulations. It should be used when undertaking significant home renovation projects that require formal documentation of scope, responsibilities, and terms. The contract includes essential provisions for project timeline, payment structure, quality standards, and warranty terms, while incorporating local building code requirements and necessary permits. It's particularly relevant for projects involving substantial modifications to residential properties and can be customized to include additional services such as interior design or project management.

1. Parties: Identification of the homeowner and the renovation contractor, including full legal names, registration numbers (for companies), and addresses

2. Background: Brief context of the renovation project and the parties' intention to enter into this agreement

3. Definitions: Key terms used throughout the contract, including 'Works', 'Project Site', 'Completion Date', 'Contract Price', and other relevant terminology

4. Scope of Works: Detailed description of the renovation works to be carried out, including specific areas of the home to be renovated

5. Contract Price and Payment Terms: Total contract value, payment schedule, deposit requirements, and payment milestones

6. Timeline and Completion: Project start date, completion date, project phases, and provisions for extensions of time

7. Contractor's Obligations: Key responsibilities including quality of work, compliance with laws, obtaining permits, worker supervision, and site management

8. Owner's Obligations: Responsibilities of the homeowner including site access, utilities provision, and timely decision-making

9. Materials and Workmanship: Standards for materials, specifications, and quality of workmanship

10. Variations: Process for requesting and approving changes to the scope of work

11. Warranties and Defects: Warranty period, defects liability period, and process for rectification of defects

12. Insurance and Indemnity: Required insurance coverage and indemnification obligations

13. Termination: Grounds for termination by either party and consequences of termination

14. Dispute Resolution: Process for resolving disputes, including mediation and arbitration procedures

15. General Provisions: Standard clauses including notices, governing law, entire agreement, and assignment