This Construction Agreement template is designed for use in Malaysia when engaging contractors for construction projects of any scale. It incorporates mandatory requirements under Malaysian law, particularly the Construction Industry Payment and Adjudication Act 2012 (CIPAA), the Street, Drainage and Building Act, and relevant safety regulations. The agreement is structured to protect both parties' interests while ensuring smooth project execution, covering essential elements from project scope and payment terms to dispute resolution mechanisms. It's particularly suitable for commercial, residential, and infrastructure projects, and can be customized based on project size, complexity, and specific requirements. The document aligns with Malaysian construction industry standards and practices, including common terms from standard forms like PAM and CIDB.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the employer/owner and contractor, including registration numbers and addresses
2. Background: Context of the agreement, including project overview and basis for entering into the contract
3. Definitions: Definitions of key terms used throughout the agreement, including technical construction terms
4. Scope of Works: Detailed description of the construction works to be performed, including general obligations of the contractor
5. Contract Sum and Payment Terms: Amount payable, payment schedule, and payment procedures in compliance with CIPAA 2012
6. Time for Completion: Project timeline, completion date, and provisions for extensions of time
7. Contractor's Obligations: Detailed responsibilities including workmanship, materials, safety requirements, and compliance with laws
8. Employer's Obligations: Responsibilities of the employer including site access, permits, and information provision
9. Variations: Procedures for handling changes to the scope of work and their cost implications
10. Quality and Standards: Required quality standards, inspections, and testing procedures
11. Defects Liability: Duration of defects liability period and obligations to rectify defects
12. Insurance and Indemnities: Required insurance coverage and indemnification obligations
13. Termination: Grounds and procedures for contract termination by either party
14. Dispute Resolution: Procedures for resolving disputes, including adjudication under CIPAA
15. General Provisions: Standard contractual provisions including notices, governing law, and assignment
1. Performance Bond: Requirements for performance security, used when project value exceeds certain thresholds
2. Advance Payment: Terms for advance payment and its recovery, used when advance payment is agreed
3. Nominated Subcontractors: Provisions regarding employer-nominated subcontractors, used when specific subcontractors are required
4. Liquidated Damages: Pre-agreed damages for delay, used when specific completion dates are critical
5. Retention Sum: Provisions for retention money, used when additional payment security is required
6. Force Majeure: Provisions for unforeseen circumstances, particularly relevant in long-term projects
7. Environmental Protection: Specific environmental obligations, used for projects with significant environmental impact
8. Anti-Corruption: Specific anti-corruption provisions, used in public or high-value projects
9. Technology and BIM: Provisions for Building Information Modeling and other technology requirements, used in complex projects
1. Schedule 1 - Scope of Works: Detailed technical specifications and scope of works
2. Schedule 2 - Contract Drawings: Approved construction drawings and design documents
3. Schedule 3 - Bill of Quantities: Detailed breakdown of quantities and rates
4. Schedule 4 - Payment Schedule: Detailed payment terms, milestones, and procedures
5. Schedule 5 - Project Timeline: Detailed construction program and milestone dates
6. Schedule 6 - Site Details: Site information, access points, and existing conditions
7. Schedule 7 - Required Insurances: Details of all required insurance policies and coverage
8. Schedule 8 - Forms and Notices: Standard forms for variations, certificates, and notices
9. Schedule 9 - Quality Assurance Requirements: Detailed quality standards and testing procedures
10. Appendix A - Special Conditions: Any special conditions or requirements specific to the project
Relevant legal definitions
Clauses
Relevant Industries
Real Estate
Infrastructure
Commercial Development
Industrial Development
Residential Development
Healthcare
Education
Hospitality
Retail
Manufacturing
Energy
Transportation
Public Sector
Mining
Telecommunications
Relevant Teams
Legal
Operations
Commercial
Procurement
Project Management
Technical
Finance
Risk & Compliance
Health & Safety
Business Development
Construction
Quality Assurance
Relevant Roles
Construction Manager
Project Director
Contract Manager
Legal Counsel
Quantity Surveyor
Project Manager
Site Engineer
Commercial Director
Procurement Manager
Risk Manager
Chief Executive Officer
Operations Director
Technical Director
Finance Director
Development Manager
Compliance Officer
Health and Safety Manager
Find the exact document you need
Home Builder Subcontractor Agreement
A Malaysian law-governed agreement between main contractor and subcontractor for residential construction works, complying with local construction and housing development regulations.
Download
Contractor Service Contract
Malaysian law-governed agreement establishing terms between a company and independent contractor, defining service provisions and relationship parameters.
Download
Independent Contractor Therapist Agreement
Malaysian-law governed agreement establishing an independent contractor relationship between a healthcare facility and a therapist.
Download
Contractor Architect Agreement
A Malaysian law-governed agreement between a client and an architect contractor defining architectural services, obligations, and commercial terms.
Download
Contract For Work For Hire
A Malaysian law-governed agreement establishing terms for commissioned work, including ownership transfer, payment, and delivery obligations.
Download
Simple Building Contract
A Malaysian law-governed construction agreement for straightforward building projects, establishing key terms between employer and contractor.
Download
Basic Independent Contractor Agreement
A Malaysian law-governed agreement establishing the terms and conditions between a business and an independent contractor, ensuring clear definition of services and compliance with local regulations.
Download
Self Employed Service Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a service provider and client company, defining services, terms, and obligations.
Download
Contractor Deposit Agreement
A Malaysian law-governed agreement establishing terms for contractor deposits in construction projects, including payment, holding, and release conditions.
Download
Developer Contractor Agreement
Malaysian-law governed agreement for engaging software development contractors, defining service terms and protecting both parties' interests.
Download
Home Contractor Contract
A Malaysian law-governed contract between homeowner and contractor for residential construction works, including terms, conditions, and regulatory compliance requirements.
Download
Standard Independent Contractor Contract
A Malaysian law-governed agreement establishing terms and conditions between a company and an independent contractor for professional services.
Download
Agreement Between Owner And Electrical Contractor
A Malaysian law-governed agreement between property owner and electrical contractor defining terms, scope, and compliance requirements for electrical installation works.
Download
Service Of Work Contract
A Malaysian law-governed agreement establishing terms and conditions for service provision between a service provider and client.
Download
Residential Building Contract Agreement
A Malaysian law-governed agreement between property owner and contractor for residential construction works, ensuring compliance with local construction regulations and standards.
Download
Agreement Between Owner And Labour Contractor
A Malaysian law-governed agreement between project owners and labor contractors establishing terms for workforce services and regulatory compliance.
Download
Massage Contractor Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a business and a massage therapist, defining service terms and operational requirements.
Download
Short Form Contractor Agreement
A streamlined contractor agreement template for Malaysian jurisdiction, designed for engaging independent contractors or service providers.
Download
Home Painting Contract
A Malaysian law-governed contract for residential painting services, establishing terms between contractors and property owners.
Download
Home Improvement Agreement
A Malaysian law-governed agreement between homeowner and contractor for residential improvement works, detailing project scope, terms, and obligations.
Download
Freelance Contractor Agreement
A Malaysian law-governed agreement establishing terms between a client and freelance contractor, defining services, payments, and obligations.
Download
Subcontractor Employment Agreement
Malaysian-law governed agreement establishing subcontractor relationship and terms of service provision.
Download
Simple Payment Agreement Contract
A Malaysian law-governed agreement establishing payment terms and obligations between parties.
Download
Independent Contractor And Non Compete
Malaysian law-compliant agreement for engaging independent contractors with non-compete provisions to protect business interests.
Download
Contractor Service Agreement
A Malaysian law-governed agreement establishing terms and conditions between a client company and an independent contractor for professional services.
Download
Consulting Agreement Contract
A Malaysian law-governed agreement defining the terms and conditions between a consultant and client, including service scope, payments, and obligations.
Download
Standard Form Of Contract For Maintenance And Renovation Works
A Malaysian standard form contract template for maintenance and renovation works, establishing terms and conditions between property owners and contractors.
Download
Standard Builders Contract
A Malaysian law-governed construction contract defining the relationship between employer and contractor for building projects, aligned with CIDB requirements.
Download
Simple Contractor Contract
A Malaysian law-governed contractor agreement establishing independent service provider relationships while ensuring legal compliance and protecting both parties' interests.
Download
Self Employed Cleaner Contract
Malaysian-compliant contract template for engaging self-employed cleaning contractors, establishing service terms and independent contractor status.
Download
Sales Subcontractor Agreement
Malaysian-law governed agreement establishing terms for sales subcontractor relationships, including commission structures, territories, and performance requirements.
Download
Percentage Agreement Contract
A Malaysian law-governed agreement establishing percentage-based commercial terms between parties, including calculation methods and payment structures.
Download
Painting Subcontractor Contract
A Malaysian law-governed contract establishing terms and conditions for painting subcontractor works in construction projects.
Download
Part Time Contractor Agreement
Malaysian-law governed agreement for engaging part-time independent contractors, defining service terms and maintaining contractor independence.
Download
General Contract For Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for service provision between a provider and client.
Download
General Contract Agreement Between Two Parties
A versatile contract template under Malaysian law establishing legal terms and conditions between two contracting parties.
Download
Contract For Cleaning Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for professional cleaning services between service providers and clients.
Download
Construction Service Contract
A Malaysian law-governed agreement establishing terms and conditions for construction services between an employer and contractor.
Download
Contract Agreement For Interior Works
A Malaysian law-governed agreement establishing terms and conditions for interior works projects, including scope, payments, and obligations of all parties.
Download
Contractor Non Solicitation Agreement
A Malaysian law-governed agreement preventing contractors from soliciting company employees, clients, or customers during and after their engagement.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)