The Building Contract Agreement serves as the primary legal instrument for construction projects in Malaysia, establishing the rights, obligations, and responsibilities of all parties involved in the construction process. This document is essential when engaging contractors for any significant construction work, whether for commercial, residential, or industrial projects. It encompasses crucial elements such as scope of works, payment terms, completion timelines, quality standards, and dispute resolution mechanisms, all aligned with Malaysian construction law and regulations. The agreement ensures compliance with local building codes, environmental requirements, and safety standards while protecting the interests of both the project owner and the contractor. It's particularly important for risk management and project governance in the Malaysian construction industry, where specific regulatory requirements must be met.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identification and details of the Employer and the Contractor, including registration numbers and addresses
2. Background: Context of the agreement, including project overview and basis for entering into the contract
3. Definitions and Interpretation: Detailed definitions of terms used throughout the agreement and rules for contract interpretation
4. Scope of Works: Detailed description of the construction works to be performed, including specifications and standards
5. Contract Sum and Payment Terms: Total contract value, payment schedule, and mechanisms for progress payments
6. Time for Completion: Project timeline, completion date, and provisions for extensions of time
7. Contractor's Obligations: Comprehensive list of contractor's duties, responsibilities, and performance standards
8. Employer's Obligations: Duties and responsibilities of the employer, including site access and information provision
9. Materials and Workmanship: Standards for construction materials and quality of workmanship required
10. Variations: Procedures for handling changes to the scope of work and price adjustments
11. Insurance and Indemnities: Required insurance coverage and indemnification obligations
12. Defects Liability: Duration and scope of defects liability period and rectification procedures
13. Termination: Grounds and procedures for contract termination by either party
14. Dispute Resolution: Procedures for resolving disputes, including mediation and arbitration
15. General Provisions: Standard contract clauses including notices, governing law, and entire agreement
1. Performance Bond: Required when project value exceeds certain threshold or when specifically requested by employer
2. Advance Payment: Included when advance payment is to be made to the contractor
3. Nominated Sub-contractors: Used when specific sub-contractors are to be nominated by the employer
4. Liquidated Damages: Specific provisions for compensation in case of delay or non-performance
5. Environmental Protection: Additional environmental requirements for environmentally sensitive projects
6. Site Safety and Security: Enhanced safety provisions for high-risk construction projects
7. Force Majeure: Detailed provisions for handling unforeseen circumstances and their impact
8. Intellectual Property Rights: Required when design elements or proprietary methods are involved
9. Confidentiality: Included for projects involving sensitive information or proprietary designs
1. Schedule 1 - Contract Drawings: Detailed architectural and engineering drawings for the project
2. Schedule 2 - Bills of Quantities: Itemized list of quantities and rates for all construction works
3. Schedule 3 - Project Specifications: Detailed technical specifications for materials and workmanship
4. Schedule 4 - Project Timeline: Detailed construction schedule with milestones and completion dates
5. Schedule 5 - Payment Schedule: Breakdown of payment installments and milestone payments
6. Schedule 6 - Site Information: Details of the construction site, including surveys and soil reports
7. Schedule 7 - List of Approved Materials: Specified materials and approved manufacturers/suppliers
8. Schedule 8 - Forms and Certificates: Standard forms for variations, completion certificates, and other documentation
9. Schedule 9 - Insurance Requirements: Detailed insurance specifications and coverage requirements
10. Appendix A - Special Conditions: Project-specific conditions and requirements
11. Appendix B - Quality Assurance Plan: Detailed quality control procedures and requirements
Relevant legal definitions
Clauses
Relevant Industries
Construction
Real Estate Development
Infrastructure
Commercial Property
Residential Property
Industrial Development
Public Works
Architecture
Engineering Services
Project Management
Relevant Teams
Legal
Operations
Construction
Project Management
Commercial
Procurement
Risk Management
Quality Assurance
Technical Services
Property Development
Contract Administration
Relevant Roles
Project Manager
Construction Manager
Contract Administrator
Legal Counsel
Development Director
Chief Operating Officer
Procurement Manager
Risk Manager
Site Supervisor
Quality Control Manager
Commercial Director
Technical Director
Project Architect
Quantity Surveyor
Construction Engineer
Find the exact document you need
Home Builder Subcontractor Agreement
A Malaysian law-governed agreement between main contractor and subcontractor for residential construction works, complying with local construction and housing development regulations.
Download
Contractor Service Contract
Malaysian law-governed agreement establishing terms between a company and independent contractor, defining service provisions and relationship parameters.
Download
Independent Contractor Therapist Agreement
Malaysian-law governed agreement establishing an independent contractor relationship between a healthcare facility and a therapist.
Download
Contractor Architect Agreement
A Malaysian law-governed agreement between a client and an architect contractor defining architectural services, obligations, and commercial terms.
Download
Contract For Work For Hire
A Malaysian law-governed agreement establishing terms for commissioned work, including ownership transfer, payment, and delivery obligations.
Download
Simple Building Contract
A Malaysian law-governed construction agreement for straightforward building projects, establishing key terms between employer and contractor.
Download
Basic Independent Contractor Agreement
A Malaysian law-governed agreement establishing the terms and conditions between a business and an independent contractor, ensuring clear definition of services and compliance with local regulations.
Download
Self Employed Service Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a service provider and client company, defining services, terms, and obligations.
Download
Contractor Deposit Agreement
A Malaysian law-governed agreement establishing terms for contractor deposits in construction projects, including payment, holding, and release conditions.
Download
Developer Contractor Agreement
Malaysian-law governed agreement for engaging software development contractors, defining service terms and protecting both parties' interests.
Download
Home Contractor Contract
A Malaysian law-governed contract between homeowner and contractor for residential construction works, including terms, conditions, and regulatory compliance requirements.
Download
Standard Independent Contractor Contract
A Malaysian law-governed agreement establishing terms and conditions between a company and an independent contractor for professional services.
Download
Agreement Between Owner And Electrical Contractor
A Malaysian law-governed agreement between property owner and electrical contractor defining terms, scope, and compliance requirements for electrical installation works.
Download
Service Of Work Contract
A Malaysian law-governed agreement establishing terms and conditions for service provision between a service provider and client.
Download
Residential Building Contract Agreement
A Malaysian law-governed agreement between property owner and contractor for residential construction works, ensuring compliance with local construction regulations and standards.
Download
Agreement Between Owner And Labour Contractor
A Malaysian law-governed agreement between project owners and labor contractors establishing terms for workforce services and regulatory compliance.
Download
Massage Contractor Agreement
A Malaysian law-governed agreement establishing an independent contractor relationship between a business and a massage therapist, defining service terms and operational requirements.
Download
Short Form Contractor Agreement
A streamlined contractor agreement template for Malaysian jurisdiction, designed for engaging independent contractors or service providers.
Download
Home Painting Contract
A Malaysian law-governed contract for residential painting services, establishing terms between contractors and property owners.
Download
Home Improvement Agreement
A Malaysian law-governed agreement between homeowner and contractor for residential improvement works, detailing project scope, terms, and obligations.
Download
Freelance Contractor Agreement
A Malaysian law-governed agreement establishing terms between a client and freelance contractor, defining services, payments, and obligations.
Download
Subcontractor Employment Agreement
Malaysian-law governed agreement establishing subcontractor relationship and terms of service provision.
Download
Simple Payment Agreement Contract
A Malaysian law-governed agreement establishing payment terms and obligations between parties.
Download
Independent Contractor And Non Compete
Malaysian law-compliant agreement for engaging independent contractors with non-compete provisions to protect business interests.
Download
Contractor Service Agreement
A Malaysian law-governed agreement establishing terms and conditions between a client company and an independent contractor for professional services.
Download
Consulting Agreement Contract
A Malaysian law-governed agreement defining the terms and conditions between a consultant and client, including service scope, payments, and obligations.
Download
Standard Form Of Contract For Maintenance And Renovation Works
A Malaysian standard form contract template for maintenance and renovation works, establishing terms and conditions between property owners and contractors.
Download
Standard Builders Contract
A Malaysian law-governed construction contract defining the relationship between employer and contractor for building projects, aligned with CIDB requirements.
Download
Simple Contractor Contract
A Malaysian law-governed contractor agreement establishing independent service provider relationships while ensuring legal compliance and protecting both parties' interests.
Download
Self Employed Cleaner Contract
Malaysian-compliant contract template for engaging self-employed cleaning contractors, establishing service terms and independent contractor status.
Download
Sales Subcontractor Agreement
Malaysian-law governed agreement establishing terms for sales subcontractor relationships, including commission structures, territories, and performance requirements.
Download
Percentage Agreement Contract
A Malaysian law-governed agreement establishing percentage-based commercial terms between parties, including calculation methods and payment structures.
Download
Painting Subcontractor Contract
A Malaysian law-governed contract establishing terms and conditions for painting subcontractor works in construction projects.
Download
Part Time Contractor Agreement
Malaysian-law governed agreement for engaging part-time independent contractors, defining service terms and maintaining contractor independence.
Download
General Contract For Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for service provision between a provider and client.
Download
General Contract Agreement Between Two Parties
A versatile contract template under Malaysian law establishing legal terms and conditions between two contracting parties.
Download
Contract For Cleaning Services Agreement
A Malaysian law-governed agreement establishing terms and conditions for professional cleaning services between service providers and clients.
Download
Construction Service Contract
A Malaysian law-governed agreement establishing terms and conditions for construction services between an employer and contractor.
Download
Contract Agreement For Interior Works
A Malaysian law-governed agreement establishing terms and conditions for interior works projects, including scope, payments, and obligations of all parties.
Download
Contractor Non Solicitation Agreement
A Malaysian law-governed agreement preventing contractors from soliciting company employees, clients, or customers during and after their engagement.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)