Construction Contract Agreement

Construction Contract Agreement Template for Ireland

Create a bespoke document in minutes, or upload and review your own.

4.6 / 5

4.8 / 5

Let's create your Construction Contract Agreement

1. Select your governing law and document type:

2. Enter your key requirements:

3. Create your document to edit, review or download

Get your first 2 documents free

Your data doesn't train Genie's AI

You keep IP ownership of your information

Key Requirements PROMPT example:

"I need a Construction Contract Agreement under Irish law for a commercial office development in Dublin, with specific provisions for phased completion and BIM requirements, planned to commence in March 2025."

Document background

The Construction Contract Agreement is a fundamental document for any construction project in Ireland, establishing the legal and commercial framework between the employer and contractor. It is essential for projects ranging from commercial developments to infrastructure works, incorporating mandatory requirements from the Construction Contracts Act 2013 and other relevant Irish legislation. The agreement covers crucial aspects including payment terms, project execution, quality standards, variations, and dispute resolution mechanisms. It should be used whenever engaging a contractor for construction works in Ireland, ensuring compliance with local building regulations, health and safety requirements, and industry standards. The document provides comprehensive protection for all parties while facilitating efficient project delivery within the Irish legal framework.

Suggested Sections

1. Parties: Identification and details of the Employer and Contractor

2. Background: Context of the agreement and brief project overview

3. Definitions and Interpretation: Definitions of key terms and interpretation rules

4. Contractor's Obligations: Primary obligations including workmanship, materials, and compliance with laws

5. Employer's Obligations: Primary obligations including site access, permits, and information provision

6. Contract Price and Payment: Payment terms, valuation mechanisms, and payment schedule in compliance with Construction Contracts Act 2013

7. Time and Programme: Completion dates, programme requirements, and extension of time provisions

8. Variations: Procedures for changes to works, valuation of variations, and authority to vary

9. Quality and Defects: Quality standards, inspection rights, and defects correction procedures

10. Health and Safety: Safety obligations, compliance with regulations, and site safety management

11. Insurance and Indemnities: Required insurance coverage and indemnification obligations

12. Termination: Grounds and procedures for contract termination by either party

13. Dispute Resolution: Procedures for dispute resolution including adjudication under the Construction Contracts Act

14. General Provisions: Standard contractual provisions including notices, governing law, and assignment

Optional Sections

1. Sectional Completion: Used when the works are to be completed and handed over in sections

2. Nominated Subcontractors: Required when employer-nominated subcontractors are to be used

3. Performance Security: Include when bonds or parent company guarantees are required

4. Price Adjustment: For longer projects where price fluctuation provisions are needed

5. Archaeological Findings: Required for projects in historically sensitive areas

6. Provisional Sums: Include when certain works cannot be precisely defined at contract formation

7. Intellectual Property Rights: When design responsibility or special IP considerations apply

8. Building Information Modelling: Required when BIM is to be used in the project

9. Sustainable Construction Requirements: For projects with specific environmental or sustainability targets

10. Liquidated Damages: When pre-determined damages for delay are to be included

Suggested Schedules

1. Schedule 1 - Contract Documents: List of all documents forming part of the contract

2. Schedule 2 - Works Description: Detailed description of the works including specifications and drawings

3. Schedule 3 - Contract Price Breakdown: Detailed breakdown of the contract price and rates

4. Schedule 4 - Programme Requirements: Detailed programming requirements and key milestone dates

5. Schedule 5 - Site Information: Information about the site including surveys and existing conditions

6. Schedule 6 - Insurance Requirements: Detailed insurance requirements and minimum coverage levels

7. Schedule 7 - Forms of Certificates: Templates for payment, completion, and other certificates

8. Schedule 8 - Key Personnel: Details of key personnel from both parties

9. Schedule 9 - Quality Management Requirements: Quality assurance and control requirements

10. Schedule 10 - Health and Safety Requirements: Detailed health and safety requirements and procedures

11. Appendix A - Form of Performance Security: Template for bonds or guarantees if required

12. Appendix B - Form of Collateral Warranty: Template for collateral warranties if required

Authors

Alex Denne

Head of Growth (Open Source Law) @ ��Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

alex.den.21@genieai.co

Relevant legal definitions

Clauses

Relevant Industries

Commercial Construction

Residential Development

Industrial Construction

Infrastructure Development

Healthcare Construction

Educational Facilities

Retail Development

Hospitality Construction

Sports Facilities

Public Works

Energy Infrastructure

Transportation Infrastructure

Mixed-use Development

Data Center Construction

Relevant Teams

Legal

Construction

Commercial

Procurement

Operations

Finance

Risk Management

Project Management

Technical

Health and Safety

Compliance

Business Development

Contract Administration

Relevant Roles

Construction Director

Project Manager

Commercial Manager

Contracts Manager

Quantity Surveyor

Construction Manager

Site Manager

Legal Counsel

Risk Manager

Procurement Manager

Operations Director

Development Manager

Technical Director

Chief Executive Officer

Finance Director

Project Engineer

Construction Lawyer

Compliance Officer

Health and Safety Manager

Find the exact document you need

Renovation Contract Agreement

An Irish law-governed agreement setting out terms and conditions for property renovation works between a property owner and contractor.

��������Ƶ

How ��������Ƶ reduced drafting time by 75% for a legal firm

Let's create your Construction Contract Agreement

Authors

Alex Denne

Find the exact document you need

Renovation Contract Agreement

Electrical Contractor Agreement

Basic Contractor Agreement

Agreement To Rescind Contract

Simple Building Contract

Construction Company Contract

Builder Client Contract

Labour Contract Form

Short Independent Contractor Agreement

Indemnity Agreement (Construction)

Indemnification Agreement (Construction)

Contractor Contract Agreement

Construction Contract Between Owner And Contractor

Non Compete With Independent Contractor

Exclusive Subcontractor Agreement

General Contractor Contract Agreement

Short Form Contractor Agreement

Cleaning Contractor Agreement

House Renovation Contract

Freelance Contractor Agreement

Subcontractor Service Agreement

Sole Trader Contract

Simple Payment Agreement Contract

Driver Contractor Agreement

Domestic Subcontract Agreement

Contractor Service Agreement

Consulting Agreement Contract

Self Employed Consultant Agreement

Salon Contract For Employees

Part Time Contractor Agreement

Independent Sales Contract

Home Remodel Contract

Framework Agreement Contract

Binding Agreement Contract

Electrical Contract Form

Subcontractor Contract Form

Model Form Contract

Landscape Contractor Contract

Independent Worker Contract

Therapist Independent Contractor Agreement

Standard Contract Form

Residential Plumber Contract Agreement

Owner Contractor Agreement

Software Developer Contractor Agreement

Residential Contractor Contract

Independent Contractor Agreement Real Estate Salesperson

Indemnity Form For Contractors

General Contractor Contract With Owner

Standard Contractor Agreement

Software Subcontractor Agreement

Simple Business Agreement Contract

Short Subcontractor Agreement

Independent Contractor Agreement Cleaning Services

Builder Agreement

Self Employed Barber Contract

Party Agreement Contract

Independent Contractor Hold Harmless Agreement

Construction Subcontractor Agreement

Work Order Contract Agreement

Civil Agreement Contract

Sales Contractor Agreement

Salon Agreement Contract

Independent Contractor Driver Agreement

Legal Agreement Contract

Social Media Contractor Agreement

Labor Agreement Contract

International Contractor Agreement

Construction Deposit Agreement

Short Form Contract

Model Agreement Contract

Independent Contractor Non Disclosure Agreement

Associate Contractor Agreement

Project Manager Contract Agreement

Third Party Contractor Agreement

��Ƶ

How ��Ƶ reduced drafting time by 75% for a legal firm

�ұ�Ծ��’s Security Promise