General Contractor Work Agreement - England and Wales

General Contractor Work Agreement for the United Kingdom

General Contractor Work Agreement Template for England and Wales

A General Contractor Work Agreement is a legally binding document used in England and Wales that establishes the terms and conditions between a client and a general contractor for construction works. It outlines the scope of work, payment terms, timeline, quality standards, and responsibilities of all parties involved. The agreement incorporates relevant construction legislation and industry standards while providing mechanisms for dispute resolution and risk allocation.

Your data doesn't train Genie's AI

You keep IP ownership of your information

Generate a Bespoke Document

1. Select your governing law:

2. Enter your key requirements:

3. Create your document to edit, review or download

Download a Standard Template

Get our England and Wales-compliant General Contractor Work Agreement

4.6 / 5

4.8 / 5

Alternatively: Run an advanced review of an existing
General Contractor Work Agreement

Let ��Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.

What is a General Contractor Work Agreement?

The General Contractor Work Agreement serves as the primary contract document for construction projects in England and Wales. It is essential when engaging a general contractor to undertake construction works, whether for new builds, renovations, or infrastructure projects. The agreement details all aspects of the construction project, including scope, cost, timeline, quality requirements, and risk allocation. It incorporates requirements from the Housing Grants, Construction and Regeneration Act 1996 and other relevant legislation, while providing clear frameworks for payment mechanisms, dispute resolution, and project management procedures.

What sections should be included in a General Contractor Work Agreement?

1. 1. Parties: Identification and details of the contracting parties, including registered addresses and company numbers

2. 2. Background: Context of the agreement, including project overview and reasons for engagement

3. 3. Definitions: Definitions of key terms used throughout the agreement

4. 4. Scope of Works: Detailed description of the works to be performed by the contractor

5. 5. Contract Price and Payment Terms: Payment amounts, schedule, mechanisms, and procedures for payment applications

6. 6. Duration and Programme: Project timeline, completion dates, and key milestones

7. 7. Contractor Obligations: Key responsibilities and duties of the contractor, including quality standards and compliance requirements

8. 8. Client Obligations: Key responsibilities and duties of the client, including site access and information provision

9. 9. Insurance and Liability: Required insurance coverage, liability limitations, and indemnities

10. 10. Health and Safety: Health and safety obligations and compliance with CDM Regulations

11. 11. Variations: Procedures for handling changes to the scope of works

12. 12. Suspension and Termination: Circumstances and procedures for suspending or terminating the contract

13. 13. Dispute Resolution: Procedures for resolving disputes, including adjudication and arbitration provisions

14. 14. General Provisions: Standard boilerplate clauses including notices, assignment, and entire agreement

What sections are optional to include in a General Contractor Work Agreement?

1. Performance Bond: Requirements for performance security, typically 10% of contract value

2. Parent Company Guarantee: Guarantee from contractor's parent company for subsidiary performance

3. Liquidated Damages: Pre-agreed damages for delay or specific performance failures

4. Collateral Warranties: Warranties to third parties such as funders or tenants

5. Defects Liability Period: Extended period for rectification of defects post-completion

What schedules should be included in a General Contractor Work Agreement?

1. Schedule 1 - Scope of Works: Detailed specification and drawings of works to be performed

2. Schedule 2 - Programme: Detailed timeline, milestone dates, and critical path information

3. Schedule 3 - Payment Schedule: Detailed breakdown of payments, rates, and payment mechanisms

4. Schedule 4 - Site Information: Details about the construction site, conditions, and access arrangements

5. Schedule 5 - Key Personnel: List of key staff, their roles, and qualifications

6. Schedule 6 - Forms of Bonds/Guarantees: Template forms for any required bonds, guarantees, or warranties

7. Schedule 7 - Insurance Requirements: Detailed insurance requirements including types and minimum coverage

8. Schedule 8 - Required Approvals: List of necessary permits, consents, and approvals

Authors

Alex Denne

Head of Growth (Open Source Law) @ ��Ƶ | 3 x UCL-Certified in Contract Law & Drafting | 4+ Years Managing 1M+ Legal Documents | Serial Founder & Legal AI Author

Cost

Free to use

Relevant legal definitions

Clauses

Relevant Industries

Real Estate
Retail
Manufacturing
Professional Services

Relevant Teams

Legal
Commercial
Procurement
Real Estate
Finance

Relevant Roles

Contract Manager
Legal Counsel
Commercial Director
Property Manager
Procurement Manager

Industries

Housing Grants, Construction and Regeneration Act 1996: Key construction legislation that governs payment terms, adjudication rights, and dispute resolution in construction contracts

Construction Act 2009: Updates and amends the 1996 Act, particularly regarding payment procedures and adjudication provisions

Supply of Goods and Services Act 1982: Establishes implied terms about quality of service and materials in contracts

Contracts (Rights of Third Parties) Act 1999: Governs how third parties may enforce terms of a contract

Consumer Rights Act 2015: Relevant if contracting with consumers, setting out consumer rights and business obligations

Unfair Contract Terms Act 1977: Restricts the use and enforceability of exclusion clauses in contracts

Health and Safety at Work etc. Act 1974: Primary legislation for workplace health and safety requirements

Construction (Design and Management) Regulations 2015: Specific health and safety regulations for construction projects, defining roles and responsibilities

Working Time Regulations 1998: Governs maximum working hours, rest periods, and holiday entitlements

Employment Rights Act 1996: Establishes basic employment rights and contractor/employee distinctions

National Minimum Wage Act 1998: Sets minimum payment requirements for workers

Equality Act 2010: Prohibits discrimination and promotes equality in the workplace

Environmental Protection Act 1990: Sets requirements for environmental protection during construction work

Control of Pollution Act 1974: Regulates noise, waste, and pollution control in construction activities

Building Act 1984: Provides framework for building regulations and control

Building Regulations 2010: Sets specific standards for building work and construction

Late Payment of Commercial Debts (Interest) Act 1998: Allows interest to be charged on late commercial payments

Value Added Tax Act 1994: Governs VAT obligations and requirements in construction contracts

Employers' Liability (Compulsory Insurance) Act 1969: Requires employers to maintain insurance against liability for employees' injuries or diseases

UK GDPR: Regulates the processing and handling of personal data

Data Protection Act 2018: Implements and supplements the UK GDPR, providing the UK's data protection framework

Find the exact document you need

No matches found.

Social Media Contract

An English law agreement establishing terms for free social media management services, including content rights and posting schedules.

��������Ƶ

How Cambridge United Uses ��������Ƶ to Speed Up Player Signings and Slash Legal Costs

Generate a Bespoke Document

Download a Standard Template

What is a General Contractor Work Agreement?

What sections should be included in a General Contractor Work Agreement?

What sections are optional to include in a General Contractor Work Agreement?

What schedules should be included in a General Contractor Work Agreement?

Authors

Alex Denne

Jurisdiction

Publisher

Document Type

Sector

Cost

Find the exact document you need

Social Media Contract

Work Contracts For Independent Contractors

Subcontractor Agreement Payment Terms

Startup Contractor Agreement

Standard General Contractor Agreement

Standard Form Of Contract For Maintenance And Renovation Works

Standard Builders Contract

Spa Independent Contractor Agreement

Sound And Light Contracting Agreement

Snow Removal Service Contract

Short Contractor Agreement

Simple Engineering Contract

Simple Contractor Contract

Short Form Subcontractor Agreement

Simple Handyman Contract

Self Employed Cleaner Contract

Salon Contract For Employees

Sales Subcontractor Agreement

Real Estate Construction Contract

Prime Contractor Agreement

Preferred Contractor Agreement

Percentage Agreement Contract

Painting Subcontractor Contract

Part Time Contractor Agreement

Non Profit Contractor Agreement

Mining Contractor Agreement

Masonry Contract Agreement

Janitorial Subcontractor Agreement

IT Contractor Contract

Independent Sales Contract

Independent Contractor Separation Agreement

Housekeeping Services Agreement Contract

House Framing Contract

House Flipping Contractor Agreement

Home Remodel Contract

General Contract For Services Agreement

General Contract Agreement Between Two Parties

Framing Contractor Contract

Framework Agreement Contract

Fence Contract Agreement

�ұ�Ծ���’s Security Promise

Your documents are private:

Your documents are protected:

Organizational security:

Templates

Contract Templates

Letter Templates

Policy Templates

Industries

Legal Services

Manufacturing

Construction

Solutions

Use Cases

Company Types

Comparisons

Business Categories

Teams

Information

Generate Legal Docs Free

��Ƶ

How Cambridge United Uses ��Ƶ to Speed Up Player Signings and Slash Legal Costs

�ұ�Ծ��’s Security Promise