The Prime Contractor Agreement is a fundamental document used in construction and infrastructure projects in India where a project owner engages a primary contractor to execute significant works. This agreement type is essential when the project requires a single point of responsibility for delivering complex construction or infrastructure works. The document comprehensively addresses project execution requirements, regulatory compliance (including Indian construction laws, labor regulations, and safety standards), risk allocation, and commercial terms. It's particularly crucial for projects where coordinated delivery, quality control, and clear accountability are paramount. The agreement includes detailed provisions for scope, timeline, payment terms, performance standards, and dispute resolution mechanisms, all aligned with Indian legal requirements and industry practices.
Your data doesn't train Genie's AI
You keep IP ownership of your information
Thank you! Your submission has been received!
Oops! Something went wrong while submitting the form.
OR
Let Ƶ's market-leading legal AI identify missing terms, unusual language, compliance issues and more - in just seconds.
1. Parties: Identifies and provides full legal details of the contracting parties (Owner/Employer and Prime Contractor)
2. Background: Provides context for the agreement and brief description of the project
3. Definitions: Defines key terms used throughout the agreement
4. Scope of Work: Detailed description of the works to be performed by the Prime Contractor
5. Contract Price and Payment Terms: Specifies the contract value, payment schedule, invoicing procedures, and payment conditions
6. Timeline and Milestones: Sets out project schedule, key milestones, and completion dates
7. Contractor's Obligations: Lists all responsibilities and duties of the Prime Contractor
8. Owner's Obligations: Specifies the responsibilities and obligations of the Owner/Employer
9. Quality Standards and Compliance: Defines quality requirements, applicable standards, and compliance obligations
10. Safety and Labor Requirements: Details safety protocols and labor law compliance requirements
11. Insurance and Indemnification: Specifies required insurance coverage and indemnification obligations
12. Warranties and Representations: States warranties provided by the Contractor and representations made by both parties
13. Dispute Resolution: Outlines procedures for resolving disputes including arbitration provisions
14. Force Majeure: Defines force majeure events and their implications
15. Termination: Specifies grounds and procedures for contract termination
16. Governing Law and Jurisdiction: Establishes applicable law and jurisdiction for the agreement
1. Subcontracting: Include when subcontracting is permitted, specifying approval requirements and contractor's liability for subcontractors
2. Intellectual Property Rights: Include when the project involves creation or use of intellectual property
3. Confidentiality: Include when sensitive information will be shared during project execution
4. Environmental Compliance: Include for projects with significant environmental impact considerations
5. Site Access and Security: Include when work is performed at owner's premises requiring specific access protocols
6. Materials and Equipment: Include when specific provisions are needed for procurement and management of materials
7. Performance Security: Include when bank guarantees or performance bonds are required
8. Variations and Change Orders: Include when flexibility is needed for scope modifications
9. Liquidated Damages: Include when specific compensation for delays or performance failures needs to be pre-agreed
10. Technology and Systems Requirements: Include for projects involving specific technical or IT systems requirements
1. Schedule A - Scope of Work: Detailed technical specifications and scope breakdown
2. Schedule B - Bill of Quantities: Itemized list of work items with quantities and rates
3. Schedule C - Project Timeline: Detailed project schedule with milestones and deadlines
4. Schedule D - Payment Schedule: Detailed payment terms, milestones, and conditions
5. Schedule E - Key Personnel: List of key personnel from both parties with roles and responsibilities
6. Schedule F - Technical Standards: Applicable technical standards and specifications
7. Schedule G - Safety Requirements: Detailed safety protocols and requirements
8. Schedule H - Forms and Procedures: Standard forms for various processes (change orders, completion certificates, etc.)
9. Schedule I - Insurance Requirements: Detailed insurance coverage requirements and limits
10. Appendix 1 - Site Details: Site information, access points, and specific site conditions
11. Appendix 2 - Permits and Licenses: List of required permits and licenses with responsibilities
12. Appendix 3 - Equipment and Materials: Specifications for equipment and materials to be used
Relevant legal definitions
Clauses
Relevant Industries
Construction
Infrastructure
Real Estate Development
Industrial Projects
Energy
Mining
Oil and Gas
Transportation
Healthcare Infrastructure
Educational Infrastructure
Commercial Development
Telecommunications Infrastructure
Urban Development
Manufacturing
Relevant Teams
Legal
Operations
Procurement
Finance
Risk Management
Commercial
Project Management
Construction Management
Technical
Health Safety and Environment
Quality Assurance
Compliance
Executive Leadership
Relevant Roles
Project Director
Construction Manager
Contract Manager
Legal Counsel
Chief Executive Officer
Chief Financial Officer
Project Manager
Commercial Director
Risk Manager
Procurement Manager
Technical Director
Operations Director
Health and Safety Manager
Quality Assurance Manager
Site Supervisor
Finance Director
Company Secretary
Compliance Officer
Find the exact document you need
Lien Contract
An Indian law-governed agreement establishing a lien right over specified property as security for an underlying obligation.
Download
Labour Contract Form
A standardized employment agreement compliant with Indian labor laws, establishing terms and conditions of employment between employer and employee.
Download
House Wiring Contract
An Indian law-governed contract for electrical wiring installation services, specifying technical requirements, safety standards, and compliance with Indian electrical regulations.
Download
Handyman Maintenance Contract
An Indian law-governed agreement between a handyman/maintenance service provider and property owner/manager, outlining maintenance services, terms, and obligations.
Download
General Contract
A versatile contract template under Indian law that establishes formal business relationships between parties, compliant with the Indian Contract Act and related legislation.
Download
Contractor Non Compete Agreement
An Indian law-compliant agreement restricting a contractor's competitive activities during their engagement period, protecting company interests while maintaining enforceability under Section 27 of the Indian Contract Act.
Download
Contractor Lien Release
An Indian legal document where a contractor waives their right to place a lien on a property after receiving payment for work performed or materials supplied.
Download
Contract With Builder
An Indian law-governed agreement between property owner and builder for construction works, compliant with RERA and construction regulations.
Download
Contractors Agreement Form
An Indian law-governed agreement establishing terms and conditions between a hiring entity and a contractor, defining their professional relationship and mutual obligations.
Download
Conditions Of Contract For (Construction)
Standard construction contract conditions template under Indian law governing rights, obligations, and procedures for construction projects in India.
Download
Construction Agreement Contract
An Indian law-governed agreement between property owner/developer and contractor establishing terms for construction works, including scope, payments, and compliance requirements.
Download
Basic Independent Contractor Agreement
An Indian law-governed agreement establishing the terms and conditions between a company and an independent contractor, defining service scope, payment terms, and contractor status.
Download
Architect Contract Agreement
An Indian law-governed agreement between an architect/architectural firm and client, defining architectural services, fees, and mutual obligations.
Download
Simple Contract Labor Agreement
An Indian law-compliant agreement between a Principal Employer and Contractor for the provision and management of contract labor services.
Download
Private Security Contract
An Indian law-governed agreement for private security services provision, compliant with PSARA 2005 and related regulations.
Download
Payment Contract Agreement
An Indian law-governed agreement establishing payment terms, schedules, and obligations between parties, ensuring compliant and secure monetary transactions.
Download
Contractor Work Contract
An India-compliant Contractor Work Contract establishing terms and conditions for independent contractor services, including scope, payment, and deliverables.
Download
Building Construction Labour Contract Agreement
An Indian jurisdiction labor contract agreement for construction projects, establishing terms between principal employers and labor contractors while ensuring compliance with local construction and labor laws.
Download
Developer Contractor Agreement
An Indian law-governed agreement establishing terms for engaging an independent developer contractor, including service scope, payments, and IP rights.
Download
Standard Form Of Agreement Between Owner And Contractor
An Indian law-governed agreement between property owner and contractor defining construction project terms, obligations, and deliverables.
Download
Turnkey Contract
An Indian law-governed contract for the complete design, construction, and delivery of a fully operational facility, where the contractor assumes total responsibility from design through commissioning.
Download
Time And Materials Contract
An Indian law-governed agreement for charging based on actual time spent and materials used in project delivery, including rates, tracking, and approval processes.
Download
Standard Renovation Contract
An Indian law-governed contract establishing terms and conditions for property renovation works between owners and contractors.
Download
Swimming Pool Contract
An Indian law-governed contract for swimming pool construction and installation, detailing specifications, responsibilities, and compliance requirements.
Download
Suppliers Contract Agreement
An Indian law-governed agreement establishing terms and conditions between a purchaser and supplier for the provision of goods or services.
Download
Service Contract Proposal
An Indian law-compliant Service Contract Proposal template outlining service arrangements, terms, and obligations between parties under Indian jurisdiction.
Download
Residential Solar Installation Contract
An Indian law-governed contract for residential solar power system installation, covering technical specifications, warranties, and regulatory compliance.
Download
Restoration Contract
An Indian law-governed contract specifying terms and conditions for property restoration work, including scope, specifications, timelines, and compliance requirements.
Download
Receipt Contract
A legally binding document under Indian law that provides formal evidence of a financial transaction or transfer of goods/services, compliant with Indian Contract Act and GST regulations.
Download
Real Estate Contractor Agreement
An Indian law-governed agreement between property owner/developer and contractor establishing terms and conditions for construction services, including scope, payments, and compliance requirements.
Download
Proposal And Contract
An Indian law-governed document combining a business proposal with binding contractual terms, establishing commercial and legal parameters for business relationships.
Download
Owner's Representative Contract
An Indian law-governed agreement appointing a representative to act on behalf of a property owner, defining their authority, responsibilities, and compensation.
Download
Masonry Contract
An Indian law-governed contract establishing terms and conditions for masonry construction work, including quality standards, specifications, and compliance requirements.
Download
Marketing Agreement Contract
An Indian law-governed agreement establishing terms between a marketing service provider and client for marketing services delivery, including scope, payments, and compliance requirements.
Download
Lump Sum Contract
An Indian law-governed fixed-price contract establishing terms for project delivery at a predetermined lump sum amount, with defined scope and milestone-based payments.
Download
Insurance Agency Agreement
An Indian law-governed agreement establishing the relationship between an insurance company and its agent, compliant with IRDAI regulations.
Download
Labour Only Subcontractor Agreement
Indian law-compliant agreement template for engaging labor-only subcontractors, ensuring compliance with local labor regulations and statutory requirements.
Download
Kitchen Renovation Contract
An Indian law-governed contract for kitchen renovation projects, defining scope, terms, and obligations between contractors and property owners.
Download
Kitchen Contract
An Indian law-governed agreement for kitchen construction or renovation services, outlining project specifications, terms, and obligations of all parties involved.
Download
Labour Supply Contract
An Indian law-governed agreement between a labor contractor and principal employer for the supply and management of contract workers.
Download
ұԾ’s Security Promise
Genie is the safest place to draft. Here’s how we prioritise your privacy and security.
Your documents are private:
We do not train on your data; ұԾ’s AI improves independently
All data stored on Genie is private to your organisation
Your documents are protected:
Your documents are protected by ultra-secure 256-bit encryption
We are ISO27001 certified, so your data is secure
Organizational security:
You retain IP ownership of your documents and their information
You have full control over your data and who gets to see it
.png)